Notices and Announcements ClassifiedsLocal MS, AL & FL Classified Ads

Untitled ADVERTISEMENT FOR BIDS VARIOUS PROJECTS FOR THE CHEROKEE COUNTY BOARD OF EDUCATION CENTRE, ALABAMA PROJECT NO. 17-225 Separate sealed proposals as described below shall be received by Mr. Mitchell Guice, Superintendent, at the Cherokee County Board Of Education, Centre, Alabama, until 2:00 PM, Thursday, March 8, 2018, then opened and read aloud. Proposal "A": Reroofing Cherokee County High School and Technical Center Proposal "B": Metal Retrofit Roofing For Gaylesville High School Proposal "C": Reroofing And New HVAC Units At Cedar Bluff High School, New Sanitary Sewer Lines At Cherokee County Technical Center, Flooring Replacement At Cherokee County High School and the Kitchen Hood Replacement At Gaylesville High School A non-mandatory Pre-Bid Conference for Proposal "C" only shall start at 10:00 AM on Friday, March 2, 2018, starting at Cedar Bluff High School then proceeding to the rest of the buildings in Proposal "C". All Contractors bidding this work shall be required to visit the site and examine all existing conditions prior to submitting their proposal. All Bidders shall have general liability and workman's compensation insurance. The projects shall be bid excluding taxes. Bids must be submitted on separate proposal forms furnished by the Architect or copies thereof. No bid may be withdrawn after scheduled closing for receipt of bids for a period of sixty (60) days. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owners judgment, the best interests of the Owner will thereby be promoted. A certified check or Bid Bond payable to the Cherokee County Board of Education in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000.00 must accompany each of the proposals. Performance and statutory labor and material payment bonds will be required at the signing of the Contracts. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect. All bidders shall show such evidence by clearly displaying current license number on the outside of the sealed envelope in which the proposal is delivered. Electronic images of the documents may be viewed on-line and printed by the Contractors and Suppliers by obtaining documents through the www.mckeeassoc.com web site, by contacting the Architect at mckeeplans@gmail.com for log-in information and password. Please provide company name, address, phone #, fax #, email address and GC License #. This is the only web site endorsed by the Architect. The Architect is unable to monitor, confirm and maintain websites that are beyond his control. Addendums shall be posted on the above web site. The Architect retains ownership and copyrights of the documents. If bidders require printed sets the following shall apply: Submit to the Architect a deposit of $50.00 per set for each Proposal. The deposit shall be refunded less shipping charges for each set returned in reusable condition within ten days after bid opening. All RFI's and RFA's regarding the bid documents shall be sent and addressed thru the following e-mail account: chapmang@mckeeassoc.com. The Architect will not accept inquires via telephone or fax. Completion Time for each project shall be as described in "Sc...

Untitled ADVERTISEMENT FOR BIDS REROOFING OF VARIOUS SCHOOL BUILDINGS FOR THE AUBURN CITY SCHOOLS AUBURN, ALABAMA PROJECT NO. 18-100 Sealed proposal shall be received by Dr. Karen T. DeLano, Superintendent, at the Auburn City Board Of Education, Auburn, Alabama, until 2:00 PM, Thursday, March 8, 2018, then opened and read aloud. A non-mandatory pre-bid conference shall be held on Wednesday, February 28, 2018 starting 10:00 AM at Auburn Jr. High School, located at 405 S Dean Rd, Auburn, AL 36830. All Contractors bidding this work shall be required to visit the site and examine all existing conditions prior to submitting their proposal. All Bidders shall have general liability and workman's compensation insurance. The project shall be bid excluding taxes. Bid must be submitted on proposal form furnished by the Architect or copies thereof. No bid may be withdrawn after scheduled closing for receipt of bids for a period of sixty (60) days. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owners judgment, the best interests of the Owner will thereby be promoted. A certified check or Bid Bond payable to the Auburn City School System in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000.00 must accompany the proposal. Performance and statutory labor and material payment bonds will be required at the signing of the Contracts. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect. All bidders shall show such evidence by clearly displaying current license number on the outside of the sealed envelope in which the proposal is delivered. Electronic images of the documents may be viewed on-line and printed by the Contractors and Suppliers by obtaining documents through the www.mckeeassoc.com web site, by contacting the Architect at mckeeplans@gmail.com for log-in information and password. Please provide company name, address, phone #, fax #, email address and GC License #. This is the only web site endorsed by the Architect. The Architect is unable to monitor, confirm and maintain websites that are beyond his control. Addendums shall be posted on the above web site. The Architect retains ownership and copyrights of the documents. If bidders require printed sets the following shall apply: Submit to the Architect a deposit of $50.00 per set. The deposit shall be refunded less shipping charges for each set returned in reusable condition within ten days after bid opening. All RFI's and RFA's regarding the bid documents shall be sent and addressed thru the following e-mail account: woodhamw@mckeeassoc.com. The Architect will not accept inquires via telephone or fax. Completion Time: Work shall be completed by July 27, 2018. Supervision: Contractor to provide Superintendent(s) to ensure proper supervision for all work for each project. Owner: Dr. Karen T. DeLano, Superintendent Auburn City Schools 855 East Samford Avenue Auburn, Alabama 36830 Phone: (334) 887-2100 Architect: McKee and Associates Architecture and Interior Design 631 South Hull Street Montgomery, Alabama 36104 Phone: (334) 834-9933 Bham News: February 21, 2018

Untitled ADVERTISEMENT FOR BIDS A NEW FOLEY K-6 SCHOOL FOR THE BALDWIN COUNTY BOARD OF EDUCATION BAY MINETTE, ALABAMA PROJECT NO. 17-226 BC# 2017591 Requirements for Pre-qualification: All potential bidders shall contact the Architect at mckeeplans@gmail.com to receive the criteria to be used for the pre-qualification of this project. (AIA Document A305 and Questionnaire). Pre-qualification proposals for the above referenced project will be received at the office of the McKee Architects, 631 South Hull Street, Montgomery, AL 36104 until, Monday, March 5, 2018, at 2:00 PM. Forms shall be e-mailed to mckeeplans@gmail.com. A list of qualified contractors shall be available from the Architect. Only Contractors who have been approved to bid pursuant to the pre-qualification procedures and criteria established by the Owner will be eligible to bid the project. All Contractors must demonstrate successful completion of similar projects on time for satisfied Owners. The Owner can at his choosing add additional Contractors after the date above. A mandatory pre-bid conference shall be held on Thursday, March 8, 2018, at 10:00 AM, at the school site located at 450 N Cedar Street, Foley, AL 36535. The sealed proposal will be received for the above referenced project by Mr. Tom Waters, Business Operations/Purchasing Manager, 2600-A North Hand Ave., Bay Minette, Alabama, 36507 until 2:00 PM, Thursday, March 22, 2018, then opened and read aloud. The project shall be bid excluding taxes. Bids must be submitted on proposal form furnished by the Architect or copies thereof. No bid may be withdrawn after scheduled closing for receipt of bids for a period of sixty (60) days. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owners judgment, the best interests of the Owner will thereby be promoted. A certified check or Bid Bond payable to The Baldwin County Board of Education in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000.00 must accompany the bidder's proposal. Performance and statutory labor and material payment bonds will be required at the signing of the Contract. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect. All bidders shall show such evidence by clearly displaying current license number on the outside of the sealed envelope in which the proposal is delivered. Electronic images of the documents may be viewed on-line and printed by General Contractors, Sub Contractors and Suppliers by obtaining documents through the www.mckeeassoc.com web site, by contacting the Architect at mckeeplans@gmail.com for log-in information and password. Please provide company name, address, phone #, fax #, email address and GC License #. This is the only web site endorsed by the Architect. The Architect is unable to monitor, confirm and maintain websites that are beyond his control. Addendums shall be posted on the above web site. The Architect retains ownership and copyrights of the documents. If bidders require printed sets the following shall apply: Submit to the Architect a deposit of $300.00 per set. The deposit shall be refunded for each set returned in reusable condition within ten days after bid opening. Al...

Untitled NOTICE TO CONTRACTORS Pre-bid meeting to be held on Monday, February 26, 2018 at 9:00 a.m., in the 1st Floor Conference Room at 320 Fountain Circle, Huntsville, AL 35801. WANTED: Sealed bids in duplicate for the construction of: Periodic Bid for Traffic Striping and Marking-2018, more particularly known as Project No. 71-18-SP24 Description of Project: Periodic Bid for striping and marking for small resurfacing projects completed by the City's Public Works Services typically using their periodic bid for resurfacing as well as occasional use by Traffic Engineering. The purpose of this bid is to provide for the expedient construction of traffic striping projects as designated by the City of Huntsville, utilizing unit prices for the commonly performed contractor work items. Construction of these projects is intended to be performed within the shortest possible time frame with the work beginning and ending on dates selected by the City of Huntsville for each work authorization. Failure to comply with the times specified in the Notice to Proceed (NTP) may, in the sole determination of the City of Huntsville, result in the contractor being prohibited from bidding on additional work for the City of Huntsville, until such time as contractor is back on schedule. The attention of all bidders is called to Code of Alabama §§ 34-8-1 and 34-8-2 (1975) and 34-8-1, 34-8-2, 34-8-4, 34-8-6, 34-8-7, 34-8-8 and 34-8-9(amended 1996) setting forth the definition of general contractor and the licensing procedures and requirements for state licensing. A copy of the above Codes may be obtained from the OWNER (City of Huntsville). No one is entitled to bid and no contract may be awarded to anyone who does not possess a valid general contractor's license and the required classification for the municipal type work to be performed. The general contractor's license and classification must appear on the outside of the bid envelope along with the general contractors name and address, project name and number and date and time of bid opening. Section 39-3-5 Code of Alabama has been amended as follows: "In awarding the Contract, preference will be given to Alabama resident contractors and a nonresident bidder domiciled in a state having laws granting preference to local contractors shall be awarded the Contract only on the same basis as the nonresident bidder's state awards contracts to Alabama contractors bidding under similar circumstances." This project, Periodic Bid for Traffic Striping and Marking-2018, more particularly known as Project No. 71-18-SP24 requires the contractor to possess a State of Alabama Classification of (HS) Highways & Streets or (MU) Municipal & Utility. After proposals are opened and read, they will be compared on the basis of the summation of the products or approximate quantities shown in Attachment "A", multiplied by the unit bid prices. In the event of a discrepancy between unit bid prices and extensions, the unit bid price shall govern. A proposal will not be considered unless signed by the bidder or his authorized agent and accompanied by cashier's check or properly signed bid bond, as required by law. In determining the successful bidder, the Owner will consider in addition to the bid prices, such responsibility factors as characteristics and responsibility, skill, experience, record of integrity in business, and of performance offered and past record of performance on Owner contracts on other similar projects. Any oth...

Untitled MORTGAGE FORECLOSURE SALE Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Chip Shots Photography, Incorporated a/k/a Chip Shots Photography, Inc. on March 20, 2008, to Aliant Bank, n/k/a USAmeriBank, which mortgage is recorded in Book LR200804, Page 4087; modified by that modification dated June 15, 2015, recorded in Book LR201563, Page 29664, in the Office of the Judge of Probate of Jefferson County, Alabama, the undersigned, as Mortgagee or Transferee, under and by virtue of the power of sale contained in the said mortgage will sell at public outcry to the highest bidder for cash in front of the main entrance of the Jefferson County Courthouse in Birmingham, Alabama, on March 15, 2018, during the legal hours of sale the following real estate situated in Jefferson County, Alabama, to wit: The East fifty (50) feet of lot five (5), in Block 708, according to the present plan of the City of Birmingham more particularly described as follows: Begin at the point of intersection of the South line of Avenue F or 6th Avenue South and the West line of 38th Street; running thence in a Southerly direction along the West of 38th Street 198.34 feet to a 20 foot alley; thence in a Westerly direction along the North line of said alley 50 feet; thence in a Northerly direction parallel with 38th Street 199.50 feet to the South line of Avenue F; thence in a Easterly direction along the South line of Avenue F 50 feet to the point of beginning; except and excluding from this conveyance that certain parcel 80 feet by 50 feet off the South end of the property described hereinabove. Together with the hereditaments and appurtenances thereunto belonging. Said property will be sold on an "AS IS, WHERE IS" basis subject to the right of way easements and restrictions of record in the Probate Office of Jefferson County, Alabama, and will be subject to existing special assessments, if any, which might adversely affect the title to the subject property. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. This Mortgage Foreclosure sale will be held on March 15, 2018, at the Jefferson County Courthouse in Birmingham, Alabama. Aliant Bank, n/k/a USAmeriBank Mortgagee or Transferee This Instrument Prepared By: Burt W. Newsome P.O. Box 382753 Birmingham, AL 35238 Attorney for Mortgagee or Transferee Bham News: Feb. 21, 28, March 7, 2018

Untitled Alabama Department of Environmental Management 1400 Coliseum Boulevard Post Office Box 301463 Montgomery, Alabama 36130-1463 PUBLIC NOTICE - 210 The Department of Environmental Management is proposing to reissue the General NPDES Permit ALG640000 regulating discharges of filter backwash, sedimentation basin wash water, and decant water from water treatment plants discharging to waters of the State of Alabama (not designated outstanding national resource water or outstanding Alabama water). Discharges from water treatment plants that use ion-exchange or reverse osmosis are not covered by this General Permit. Individual facilities and/or operations may propose to operate under this general permit, if reissued, by notifying the Alabama Department of Environmental Management and providing the required documentation. After receiving such notice of intent, the Department may regulate discharge under the General Permit. The Department has tentatively determined that the reissuance of the General Permit is consistent with the Water Quality Program regulations; and for those in the coastal area, are consistent with the Alabama Coastal Management Program. Copies of the draft permit, conditions, limitations and a fact sheet as applicable describing the methodology for setting the limitations and conditions and other applicable NPDES forms and related documents are available for public inspection electronically via http://adem.alabama.gov/newsEvents/publicNotices.cnt, and at the following location Monday - Friday (except legal holidays), 8:00 am to 5:00 pm. A nominal fee for copying and/or mailing may be charged. Arrangements for copying should be made in advance. Russell A. Kelly, Chief Permits and Services Division ADEM 1400 Coliseum Blvd. [Mailing address: PO Box 301463; Zip 36130-1463] Montgomery, Alabama 36110-2400 (334) 271-7714 Persons wishing to comment may do so, in writing, to the Department's named contact above within 30 days following the publication date of this notice. In order to affect final decisions, comments must offer technically substantial information that is applicable to the proposed permit. A written request for a public hearing may also be filed within that 30-day period and must state the nature of the issues proposed to be raised in the hearing. The Director shall hold a public hearing whenever it is found, on the basis of hearing requests, that there exists a significant degree of public interest in the permit application or draft permit. The Director may also hold a hearing if he determines that it would clarify one or more issues involved in the permit decision. After consideration of all written comments, review of any public hearing record, and consideration of the requirements of the Alabama Water Pollution Control Act, the Federal Water Pollution Control Act and applicable regulations, the Department will make a final determination. The Department will develop a response to comments, which will become part of the public record and will be available to persons upon request. Notice will be sent to any person requesting notice of the final action. The Department maintains a list of interested individuals who are mailed legal notices regarding proposed permits. If you wish to receive such notices, contact the Permits & Services Division via telephone (334-271-7714), e-mail (permitsmail@adem.alabama.gov), or postal service (P.O. Box 301463, Montgomery, AL 36130-1463). This notice is hereby given this 21st day...

Untitled ADVERTISEMENT FOR BIDS RE-BIDDING OF THE ADDITIONS, RENOVATIONS AND IMPROVEMENTS AT BEAUREGARD HIGH SCHOOL FOR THE LEE COUNTY BOARD OF EDUCATION OPELIKA, ALABAMA PROJECT NO. 17-174 The sealed proposal shall be received by Dr. James McCoy Jr., Superintendent, at the Lee County Board Of Education, Opelika, Alabama, until 2:00 PM, Tuesday, February 27, 2018, then opened and read aloud. All Contractors bidding this project shall be required to visit the site and examine all existing conditions prior to submitting their proposal. All Bidders shall have general liability and workman's compensation insurance. This project shall be bid excluding taxes. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. No bid may be withdrawn after scheduled closing for receipt of bids for a period of sixty (60) days. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owners judgment, the best interests of the Owner will thereby be promoted. A certified check or Bid Bond payable to the Lee County Board of Education in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000.00 must accompany the bidder's proposal. Performance and statutory labor and material payment bonds will be required at the signing of the Contract. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect. All bidders shall show such evidence by clearly displaying current license number on the outside of the sealed envelope in which the proposal is delivered. Electronic images of the documents may be viewed on-line and printed by General Contractors, Sub Contractors and Suppliers by obtaining documents through the www.mckeeassoc.com web site, by contacting the Architect at mckeeplans@gmail.com for log-in information and password. Please provide company name, address, phone #, fax #, email address and GC License #. This is the only web site endorsed by the Architect. The Architect is unable to monitor, confirm and maintain websites that are beyond his control. Addendums shall be posted on the above web site. The Architect retains ownership and copyrights of the documents. If General Contractors, Sub Contractors and Suppliers require printed sets the following shall apply: General Contractors requesting Contract Documents may obtain up to two (2) sets by submitting to the Architects a deposit of $250.00 per set. The deposit shall be refunded less shipping charges for each set returned in reusable condition within ten days after bid opening. All RFI's and RFA's regarding the bid documents shall be sent and addressed thru the following e-mail account: chapmang@mckeeassoc.com. The Architect will not accept inquires via telephone or fax. Completion Time: Project shall be completed in Phases. Dates for each phase shall be issued in the "Scope Of Work". Supervision: Contractor to provide Superintendent(s) to ensure proper supervision for all work. Owner: Dr. James McCoy Jr., Superintendent The Lee County Board of Education 2410 Society Hill Road Opelika, AL 36804 Phone: (334) 705-6000 Architect: McKee and Associates Architecture and Interior Design 631 South Hull Street Montgomery, Alabama 36104 Phone: (334) 834-9933 B...

Untitled ALABAMA DEPARTMENT OF ENVIRONMENTAL MANAGEMENT PO Box 301463 Montgomery, Alabama 36130-1463 (334) 271-7700 PROPOSED CONSENT ORDER Account Code: 202 Jefferson County Pursuant to the provisions of the Alabama Environmental Management Act, the Alabama Department of Environmental Management (ADEM) is proposing to issue an Order to Taylor Burton Company, Inc. - South Bend Subdivision, NPDES ALR10B723 off of Wisteria Drive, in the City of Vestavia Hills, Jefferson County, Alabama. The violations consisted of: effective BMPs had not been implemented and/or maintained; noncompliance with the requirements of ADEM NPDES construction stormwater rules. The order, if issued, would require the operator to: correct all violations; implement and maintain effective BMPs; comply with applicable ADEM rules and permit requirements; perform corrective actions; pay a civil penalty in the amount of $10,000.00. Interested persons may submit written comments, including request for a hearing, within 30 days of the publication date of this notice, to the Alabama Department of Environmental Management, attention Anthony Scott Hughes, Chief of Field Operations Division, PO Box 301463, Montgomery, Alabama 36l30-1463. The comment period shall end at the close of business 30 days from the publication date of this notice. A copy of the proposed order is available on the ADEM webpage at http://adem.alabama.gov/compInfo/adminOrders.cnt or may be obtained by written request to the above address. A nominal fee for copying may be charged. This notice is hereby given this 21st day of February, 2018, by authorization of the Alabama Department of Environmental Management. Lance R. LeFleur Director Nondiscrimination Statement: The Department does not discriminate on the basis of race, color, national origin, sex, religion, age or disability in the administration of its programs. Bham News: February 21, 2018

Untitled NOTICE OF PUBLIC HEARING BEFORE THE COUNTY COMMISSION OF JEFFERSON COUNTY, ALABAMA TO CONSIDER THE FOLLOWING ZONING PROPOSALS OR AMENDMENTS A public hearing will be held by and before the County Commission of Jefferson County, Alabama in Room 270, Commission Chamber of the Jefferson County Courthouse, 716 Richard Arrington Jr. Blvd., N Birmingham, Alabama on the scheduled dates and times listed below to consider the following proposals, amendments, supplements, changes, modification or repeal in existing zoning regulations, lines, boundaries, maps and land use in said County. The zoning proposals or changes hereinafter set out have been recommended or denied, as indicated after hearing by the Jefferson County Planning and Zoning Commission. Action of said Zoning Commission and its recommendations to the County Commission is indicated below with respect to each case that will be heard at the time and place aforesaid. Thursday, March 8, 2018 @ 9:00 A. M., Room 270, Jefferson County Courthouse Z-2018-002 Earl and Randall Lee, owners; Randall Lee, applicant requests a change of zoning on Parcel ID# 14-05-2-000-001.002 in Sec 5 Twp 16 Range 3 West from I-3 (Industrial) to A-1 (Agricultural) for future residential use. (Site Only: 1480 Brookside Road, Mount Olive, AL 35117) (MOUNT OLIVE) (1.02 Acres M/L) Recommendation: Rezone the property to R-1 in lieu of the requested A-1 NOTE: All property owners within 500 feet have been notified. Signs are posted on all property. All acreage is approximate. NOTE: The recommendation for rezoning property in no way should be construed to give, grant, or recommend approval of a subdivision plat, site plan, or other submitted plan. This is strictly a recommendation on the rezoning. NOTE: Each request for a change in zoning of the property or properties described herein permits the Jefferson County Commission to rezone the property to any suitable zoning district which may be other than that requested herein. Bham News: February 21, 2018

Untitled ADVERTISEMENT FOR BIDS ANDALUSIA RESTORATION ANDALUSIA, ALABAMA Sealed bids will be received by The Armory Commission of Alabama, at the State Military Department Building, 1720 Cong. W.L. Dickinson Drive, (P.O. Box 3711), Montgomery, Alabama, until 2:00 p.m., Central time, Thursday, March 15, 2018, for Andalusia Restoration, Andalusia, AL (IFB# AC-18-B-0016-S), at which time they will be publicly opened and read in the Second Floor Classroom (Room 201), of the State Military Department, 1720 Cong. W.L. Dickinson Drive, Montgomery, Alabama. Certified checks or bid bonds payable to The Armory Commission of Alabama in an amount not less than five (5) per cent of the amount of the bid, but in no event more than $10,000.00 per project, must accompany the bidder's proposal. Completed Disclosure Statements are preferred to accompany the proposal. Performance and Payment bonds will be required at the signing of the contract. All bidders bidding in amounts exceeding $50,000.00 must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975. Plans and specifications are open to public inspection at the State Military Department, 1720 Cong. W.L. Dickinson Drive, State Property and Disbursing Office, Montgomery, AL 36109. Point of contact: Eric Holt, kenneth.e.holt2.nfg@mail.mil. Plans and specifications may be obtained from the Architects, Casey Ivy at Seay Seay & Litchfield, P.C., 1115 South Court Street, Montgomery, AL 36104, 334-263-5162, FAX 334-263-5170, upon deposit of $300.00 per set, which will be refunded in full upon return of documents in good condition within ten (10) calendar days of the bid date. Questions should be addressed, in writing, to Casey Ivy at Seay Seay & Litchfield, P.C., civey@sslarch.com. Only those bidders who have officially received "Bid Documents" from Seay Seay & Litchfield, P.C. will be included on the distribution lists as "official plan holders" for Addenda or other project information during the bidding period. Any prospective bidders other than "official plan holders" must notify, in writing, Seay Seay & Litchfield, P.C., of their intent to bid the project by 2:00 p.m., CDT, Thursday, March 8, 2018. A Pre-Bid Conference will be conducted at 9:00 a.m., Tuesday, February 27, 2018 at the Andalusia Armory, 1011 Prestwood Bridge Road, Andalusia, AL 36421. All bidders are strongly encouraged to attend. Any errors or omissions made as a result of not attending will not be grounds for additional compensation. MARK A. WEEKS State Property and Disbursing Officer Bham News: February 21, 28, March 7, 2018