Transcription

2 house construction cover In consideration of you agreeing to pay us the premium in the schedule, we agree to provide the insurance set out below. headings In this policy, headings are inserted for convenience and reference only and shall not affect the clause s interpretation. definitions Wherever these words are used in the policy in bold, this is what they mean. These definitions also apply to any derivatives of the words defined: accidental: a happening or event which is unexpected and unintended from the insured s point of view. actual value: the value calculated by deducting depreciation for age and use from the new replacement cost of insured property affected. bodily injury: a. accidental death of, or bodily injury to any person (including sickness, disease, disability, shock, fright, mental anguish or mental injury); b. false arrest or false imprisonment; malicious prosecution or malicious humiliation; c. defamation, or publication in violation of any individual s right to privacy, except: i ii defamation where you know the statement is false; defamation or publication made in the course of, or relating to, advertising, broadcasting or telecasting activities conducted by you, or on your behalf; d. wrongful entry or eviction, or other invasion of the right of private occupancy; e. battery or assault not committed by, or at your direction (unless committed for the purpose of preventing or eliminating danger to persons or property). contract: the contract between the principal and the contractor to perform the contract works. contract site: the location referred to in the contract at which the contract works are to be completed. contract works: the whole of the works, whether temporary or permanent, to be performed by you, as described in the contract, which is the subject of this insurance, including all materials and items to be incorporated therein. construction period: the period commencing on the date shown in the schedule and finishing: a. Partial completion with respect to that portion only of the contract works: at the time a partial practical completion certificate is issued; or at the time that portion of the contract works is occupied, taken over or taken into use by the purchaser, principal or authorised person, whichever is the earlier; or b. Completion at the time a practical completion certificate is issued; or at the time the contract works are practically complete except for minor omissions and minor defects which do not prevent the contract works from being reasonably capable of being used for their intended purpose; or at the time the contract works are occupied, taken over or taken into use by the purchaser, principal or authorised person whichever is the earliest; or c. Speculative project with respect to any speculative project where there is no agreement to purchase, at the time 95% of the project price has been expended on the contract works and the contract works are made available for public viewing; or d. Scheduled date on the finishing date shown in the schedule This date may be extended beyond the date shown in the schedule for the express purpose of completing the contract works, provided we agree in writing prior to the finishing date, and you agree to pay any additional premium required whichever applies first. construction plant: tools, plant or equipment, site encampments or hoardings used for the purpose of carrying out the contract works, excluding any plant or equipment forming, or to form, a permanent part of the contract works.

3 your house construction policy excess: the amount referred to in the schedule which we do not insure. first insured: the first named person or entity listed in the schedule as insured. immediately arising: the event occurring immediately prior to the loss, and if there is a chain of events, the last event occurring immediately prior to the loss. insured property: the contract works; and any other property shown in the schedule once it becomes the responsibility of the contractor insured. liable: legally liable according to the law of New Zealand. loss: accidental physical loss or accidental physical damage. maintenance period: the period commencing when any part of the contract works is put into service, taken over, occupied or issued with a certificate of partial or practical completion; and finishing: at the end of the Maintenance or Defects Liability Period referred to in the contract; or at the end of the period shown in the schedule, whichever is the earlier. Defects Liability Period shall have the same meaning. natural disaster: earthquake shock, earthquake fire, tsunami, volcanic eruption, subterranean fire, and hydrothermal activity. occurrence: an event (including continuous or repeated exposure to conditions), or a series of events resulting from, or attributable to, one source or original cause. period of insurance: both the construction period and the maintenance period. property damage: a. accidental physical loss or accidental physical damage to any tangible property, including subsequent loss of use; and/or b. accidental loss of use of tangible property which has not suffered physical loss or physical damage. proximately caused: the active and efficient cause that sets in motion a train of events which brings about the loss. regions and districts: the area of land in the regions and districts defined in the Department of Survey and Land Information Infomap 9B dated June 99. schedule: the current Schedule to this policy issued to you. sum insured: the limit of our liability in New Zealand dollars for each Item as stated in the schedule. vehicle: any type of machine on wheels, or tracks, made or intended to be propelled by its own power, or towed thereby. we; our; us; company: NZI, a business division of IAG New Zealand Limited. you; your; insured: the person(s) or entity(s) named in the schedule: a. but only in their capacity as principal or main contractor; and b. only in their capacity as sub contractor, where shown in the schedule. including: any director, employee or partner there of, but only while acting within the scope of their duties in that capacity, for their respective rights and interests. section one: construction insuring clauses During the construction period We will indemnify you against loss to insured property occurring at the contract site during the construction period. During the maintenance period We will indemnify you during the maintenance period for your legal liability to rectify loss to insured property under the Maintenance or Defects Liability Conditions of the contract, provided the loss is discovered during the maintenance period, and: a. arises out of the contract works during the construction period; or b. arises out of your operations whilst executing work under the Maintenance or Defects Liability Conditions of the contract; or c. occurs to property forming part of the contract works, which is incomplete, not built, or upon which work is being carried out for the purpose of completion following issuance of a partial or practical completion certificate.

4 house construction cover Additional items These Additional Items only apply if shown in the schedule. Where there is a loss covered by or above, this policy is extended to indemnify costs and expenses necessarily incurred up to the sum insured for each of the following Item(s) shown in the schedule: a. Principal s Supplied Materials being materials and items supplied by the principal to the contractor free of charge for inclusion in the contract works, provided they were not in their final position when supplied. b. Removal of Debris being all costs necessarily incurred to dismantle, demolish and remove the debris, and prepare the contract works for rectification of the loss. c. Professional Fees being architects, surveyors, consulting engineers, clerk of works and other fees incurred by you which are necessary to rectify the loss (but excluding any fees for the preparation of a claim or estimate of fees). d. Increased Costs During Construction being the costs incurred for variations and fluctuations in the contract price, and/or increases in the costs of labour and materials during the construction period. e. Escalation During Reconstruction being the actual amount by which the costs of reconstruction of the contract works exceed the initial costs, provided that reconstruction is completed without delay. basis of settlement In the event of loss, the basis of settlement shall be: a. where the insured damage can be repaired,the cost of repairs necessary to restore the insured property to its condition immediately before the loss; Where the cost of repair equals or exceeds the actual value immediately before the loss of the insured property affected, settlement shall be made on the basis provided for in b. b. where the insured damage is not repairable, the actual value immediately before the loss of the insured property; to the extent that: i the loss claimed had to be borne by you; and ii the loss is in respect of insured property included in the calculation of the sum(s) insured. We will indemnify you by: a. cash payment; or b. replacement; or c. repair at our option. The excess shall be deducted from each adjusted loss for each event or series of losses from the same event. A series of losses arising from subsidence, erosion, flood, inundation, landslip, cyclone, storm, tempest,or earthquake during any period of 7 consecutive hours will be treated as one event for the purpose of applying the excess. The most we will pay: for each Item is the sum insured plus GST; under this policy is the TOTAL SUM INSURED shown in the schedule plus GST. exclusions This policy does not insure: a. loss proximately caused by: i faulty or defective workmanship or material; or ii wear and tear, corrosion, erosion, or the action of normal atmospheric conditions; b. loss to mechanical or electrical items incorporated in the contract works proximately caused by their operation, or mechanical or electrical failure, derangement, breakdown, or pressure explosion; c. mechanical or electrical failure, derangement or breakdown of construction plant; d. loss which is a gradual deterioration of the insured property, or any part of it; These exclusion(s) (a)-(d) shall be limited to the: item of construction plant; or part of the structure or contract works directly affected, and shall not extend to other insured property which is affected as a result, (if any). loss proximately caused by fault, defect, or omission in design, plan, specification, sequence, procedure or programme. loss immediately arising from total or partial cessation of the contract works. loss arising out of or resulting from rot, mould, mildew, fungi or the action of micro organisms.

5 your house construction policy NOTE: These extensions must be selected by you and shown in the schedule of the policy. They are not automatic. This section only applies if shown in the schedule. 5 loss of files, deeds, evidence of debt, bonds, bills of exchange, promissory notes, cash, bank notes, cheques, securities or money, stamps, account or computer records. 6 disappearance or shortage of insured property where that loss is revealed only by the taking of an inventory or stocktaking. 7 consequential economic loss of any kind or description, including (without limitation) penalties for non-completion or delay in completion or non-compliance with contract conditions. 8 loss to any structure or property already at the contract site before commencement of the contract works. 9 0 A loss to: a. any vehicle; or b. construction plant; or c. tyres or tracks, unless as a result of other insured loss to a vehicle/mobile plant; or d. any aircraft, waterborne vessel or craft; or e. employees personal effects or hand tools. extra charges for overtime, night work, work on public holidays, express delivery or airfreight, unless such charges are reasonable, and incurred solely for the purpose of minimising further loss to the insured property following an insured loss. loss to insured property during transit not on the contract site. optional extensions Overtime & express delivery Where shown in the schedule, this section of the policy is extended to cover the additional costs incurred in rectifying the loss in the most expeditious time, including: the cost of penal rates of pay; and express delivery and airfreight within New Zealand Provided, however, we will not pay more than 0% of ordinary labour, road carriage charges or ordinary costs. Exclusion 0 is modified accordingly. C D Transit Where shown in the schedule, this section of the policy is extended to include loss of insured property during: storage at a place other than the contract site; and transit within New Zealand by road, rail, airfreight, inter-island ferry, or containerised shipping between New Zealand ports. Exclusion is modified accordingly. Natural Disaster Where shown in the schedule, this section of the policy is extended to include loss caused by earthquake, but excluding any damage for which compensation is payable under any Act of Parliament. General Exclusion shall not apply. For the purpose of this Extension only: Excess In respect of each location at which a loss occurs, the excess for each Area, shall be deducted from each adjusted loss: Area (a) The regions of Northland, Auckland, Waikato, Otago and Southland and the districts of Timaru and Waimate. Area (b) The regions of Bay of Plenty, Gisborne, Hawkes Bay, Taranaki, Manawatu, Wanganui, Tasman, West Coast and Canterbury excluding the districts of Timaru and Waimate. Area (c) The regions of Wellington, Nelson and Marlborough. B Overseas airfreight expenses Where shown in the schedule, this policy is extended to include the cost of airfreight charges necessarily and reasonably incurred in rectifying the loss, provided that the airfreight carriage is by a recognised regular scheduled airline service and not carriage by an aircraft chartered for that purpose. Exclusion 0 is modified accordingly.

6 house construction cover section two: public liability insuring clauses A Public Liability We will indemnify you for all sums you become liable to pay arising from: a. bodily injury; and / or b. property damage happening during the period of insurance resulting from an occurrence in New Zealand in connection with the contract works. Employees Vehicles Extension Exclusion a. does not apply to liability for property damage to any motor vehicle or motor cycle belonging to, or in the charge of, or under the control of, any of your employees or agents in a private capacity (and not owned by you, or any member of your family ordinarily living with you). Carparks Extension Exclusion a. ii does not apply to liability for property damage to property in any car park operated by you for the contract works. Overseas Visits Extension Section Two is extended to indemnify you for all sums you become liable to pay arising from bodily injury and/or property damage which happens during the period of insurance provided that: a. it results from an occurrence anywhere in the world in connection with any business trip by you solely in connection with the contract works; and b. you are a New Zealand Resident and normally live in New Zealand at the time of the occurrence; and c. the indemnity under this extension does not extend to liability in connection with the actual carrying out of any tangible part of the contract works or you engaging in any physical or manual work; and d. with respect to occurrences in the United States of America and Canada (including their dependencies, mandated territories and protectorates): this extension does not apply to liability in connection with seepage, pollution or contamination of any kind; and this extension does not apply to liability arising from any premises owned, or leased to another party, by you in those countries; and Defence Costs are deemed to be included within the sum insured referred to in LIMITS OF INDEMNITY and not in addition to it. For the purpose of this extension only, the definition of liable is extended to the legal liability according to the law of the country or state where the occurrence takes place. Mechanical Plant and Cranes Extension Section Two is extended to include liability resulting from the use by you of mechanical plant or machinery, including cranes and mobile cranes, but only whilst on, or adjacent to, the contract site. Exclusion a. is modified accordingly Removal of Support Extension Section Two includes liability arising from: a. bodily injury; and / or b. property damage happening during the period of insurance resulting from an occurrence at the contract site in connection with: vibration of; or removal or weakening of; or interference with the support of land or buildings which are not part of the insured property. The indemnity provided by this clause shall not exceed in the aggregate during the period of insurance $50,000, unless a different amount is shown in the schedule for this extension. An excess of $5,000 shall apply for each occurrence, unless a different amount is shown in the schedule for this extension. Exclusion e. does not apply to this extension. 5

7 your house construction policy Forest and Rural Fires Act Extension We will indemnify you for: a. levies imposed by a fire authority under the Forest and Rural Fires Act 977 and apportioned to you, (but excluding levies under Section 5); and b. liability for costs and losses recoverable under section of the Forest and Rural Fires Act 977. Provided that: the costs are in connection with a fire, or threat of fire, that occurs during the period of insurance, and the costs and losses result from an occurrence in New Zealand. Provided however that the indemnity provided by this extension shall not exceed for each occurrence $50,000 unless a different amount is shown in the schedule for this extension, which ever is the greater. This extension is deemed to apply whether property damage has occurred or not, and exclusion 8 shall not apply to this extension. An excess of $,000 shall apply for each occurrence unless a different amount is shown in the schedule for this extension. Exclusion d. does not apply to this extension. limits of indemnity Limits Unless otherwise stated in the extension: a. The maximum indemnity payable by us for each occurrence during the period of insurance shall not exceed the limit shown in the schedule for each extension; b. Defence Costs shall be paid in addition to the limit set out in a. above; c. The excess shown in the schedule shall be deducted from the amount payable for each occurrence. Discharge of Liability B Defence Costs We will indemnify you for all legal costs and expenses reasonably and properly incurred in defending any legal action against you arising out of bodily injury or property damage indemnifiable under this section of the policy, even if the legal action appears groundless. We may at any time elect to pay you the sum insured applicable under this section of the policy, or any lesser sum for which the claim against you can be settled, and upon payment we shall be under no further liability to you under this policy except for Defence Costs already incurred up until the time of payment. Cross Liability NOTE: This extension must be selected by you and shown in the schedule of the policy. It is not automatic. This section only applies if shown in the schedule. optional extension Defective Design Where shown in the schedule, we will indemnify you for all sums you become liable to pay arising from: a. bodily injury; and/or b. property damage happening during the period of insurance resulting from an occurrence in New Zealand in connection with any defective: i design; or ii formula; or iii specification; or iv plan; or v pattern prepared by you for the contract works. The indemnity provided by this extension shall not exceed in the aggregate during the period of insurance $50,000. Defence Costs are included in this figure and are not in addition to it. This section insures all insureds separately. PROVIDED that our liability shall not exceed the limit shown in the schedule in respect of the aggregate of all sums for which all insureds are liable. exclusions There is no indemnity under this section of the policy: For liability created by an express term of a contract, where that liability exceeds what: a. The common law; and b. The statue law, imposes on contracting parties in those circumstances. This exclusion does not apply to liability arising out of the use of property under an agreement entered into by the insured for the hire, lease, or rental of any property to the insured. Provided that this exception to this exclusion does not apply to liability: i for property damage to any of the property the subject of the agreement; 6

8 house construction cover ii arising from any provision in the agreement for the insured to arrange insurance over the property which is the subject of the contract. For liability arising from bodily injury to any person: a. arising out of, and in the course of, employment of that person by you; or b. who is a member of your family ordinarily residing with you; For liability arising from property damage: a. to property: i belonging to; or held under a hire purchase agreement by; or held under a conditional purchase agreement by; or hired by; or leased by; or rented by; or ii lent to; or in the possession or control of you or any member of your family ordinarily residing with you; b. to that part of any property on which you are, or have been, working, if the property damage is caused directly by the work done to that part. However, this exclusion b. does not apply to property damage to any other separate and identifiable components of that property not worked on; c. to any part of property insured under Section One of this policy. For liability in connection with: a. the ownership, possession or use by you, or on your behalf, of any vehicle. PROVIDED this exclusion a. shall not apply to the loading and unloading of a vehicle, and the bringing to and taking away of a load from a vehicle at the contract site; b. i the ownership, possession or use by you, or on your behalf, of any watercraft, or thing made or intended to float or travel on water; ii work undertaken by you to any watercraft, or thing made or intended to float or travel on water; c. i the ownership, possession or use by you, or on your behalf, of any aircraft, or thing made or intended to travel through air or space; ii work undertaken by you to any aircraft, or thing made or intended to travel through air or space; d. i any defective: design; or formula; or specification; or plan; or pattern prepared by you; ii the giving of advice; or the administering of medical treatment by you or anyone on your behalf. PROVIDED this exclusion d. ii shall not apply to any of your employees acting in the capacity of an industrial nurse; e. vibration of; or removal or weakening of; or interference with the support of land or buildings; For liability proximately caused by : a. seepage, pollution, or contamination, (including the cost of removing, nullifying or cleaning up). Unless the seepage, pollution or contamination occurs during the period of insurance and is caused by a sudden, unintended and unexpected occurrence during the same period of insurance, b. mining, processing, transporting, distributing or storing asbestos; c. manufacturing or processing materials containing asbestos; d. any process of decontamination, treatment or control of asbestos; e. the presence of asbestos in any building or structure; f. asbestos pollution or contamination (notwithstanding the proviso to 5 a. above); For liability determined by a judgement (including the costs and expenses arising out of the litigation leading to the judgement) of any court other than a New Zealand Court, unless that judgement is enforceable by a New Zealand Court; For liability in respect of any fine or penalty imposed on you, or any punitive or exemplary damages awarded against you. For liability arising under the Forest and Rural Fires Act

9 your house construction policy general exclusions applicable to all parts of the policy A B This policy does not indemnify: loss or liability directly or indirectly caused by or in connection with war, invasion, act of foreign enemy, hostilities (whether war is declared or not), civil war, rebellion, revolution, insurrection or military or usurped power, confiscation, nationalisation, requisition or destruction by or under the order of any Government or Public Authority. loss or liability proximately caused by or immediately arising from ionising radiation or contamination by radioactivity. loss or liability proximately caused by Natural Disaster. loss, damage, liability, prosecution or expense of any type connected in any way with an internal part of a building or structure being wet, damp or moist that is caused directly or indirectly by: a. faulty design or faulty specification, including faulty sequence, procedure or programme, or b. faulty materials, or c. faulty workmanship when it was constructed or altered. Terrorism Exclusion Notwithstanding any provision in the policy to the contrary, the policy excludes death, injury, illness, loss, damage, cost, expenses or liability, of any nature whatsoever, directly or indirectly caused by, or in connection with an Act of Terrorism. Act of Terrorism means: an act, including but not limited to the use of force or violence and/ or threat thereof, of any person or group(s) of persons, whether acting alone or on behalf of or in connection with any organisation(s) or C government(s), which from its nature or context is done for, or in connection with, political, religious, ideological, ethnic or similar purposes or reasons, including the intention to influence any government and/or to put the public, or any section of the public, in fear. Electronic Data Exclusion Notwithstanding any provision in the policy to the contrary, the policy excludes loss of or damage to Electronic Data, and any liability arising from this, directly or indirectly caused by, or in connection with a Computer Virus. This includes loss of use, reduction in functionality or any other associated loss or expense in connection with the Electronic Data. However, this exclusion does not apply to resultant physical damage to other insured property, which is not otherwise excluded. Electronic data means facts, concepts and information converted to a form useable for communications interpretation or processing by electronic and electromechanical data processing or electronically controlled equipment. It includes programs, software and other coded instructions for the processing and manipulation of data or the direction and manipulation of such equipment. Computer Virus means a set of corrupting, harmful or otherwise unauthorised instructions or code including a set of maliciously introduced unauthorised instructions or code, programmatic or otherwise, which propagate themselves through a computer system or network of whatsoever nature. This includes but is not limited to Trojan Horses, Worms and Time or Logic Bombs. claim conditions applicable to all parts of the policy Notification If you suffer any loss likely to give rise to a claim under this policy, or if you become aware of any potential liability likely to give rise to a claim under this policy; You shall at your expense: a. immediately notify us by fax or by telephone or via AMI Insurance Limited; b. take prompt steps to minimise the loss, and avoid any further loss; c. take prompt steps to minimise any liability, and avoid any further liability; d. if criminal offending is suspected, lay a complaint with the police; e. take reasonable steps to obtain details of any other person, property or vehicle involved, and any witnesses; 8

10 house construction cover You shall not: f. dispose of any insured property which is intended to be the subject of a claim; g. admit responsibility for any liability or do or say anything which may prejudice our ability to defend a claim against you or pursue recovery under subrogation. Repairs You may proceed with repairs, without prejudice to our liability under the policy, if a. and b. above are complied with. How to claim If you wish to make a claim under this policy, you shall: a. complete in full our Claim Form as soon as practicable after the loss; b. provide free access to examine and assess any loss or liability; c. authorise the disclosure of your personal information held by other parties relating to the claim; d. preserve the parts affected and make them available for inspection by us; e. forward any letter of demand or court documents to us immediately; f. provide any other information or assistance we reasonably require to process the claim; We will not be liable to make any payment under this policy unless you have produced to our reasonable satisfaction all accounts, 5 6 invoices, receipts, breakdown of costings and other documentation supporting amounts expended, or indicating that repairs have been effected or replacement has taken place. g. if requested by us; provide a statutory declaration to verify the loss or liability; submit to cross-examination under oath by any person we nominate. Control of Claim After we have accepted a claim, we have the sole right, at our expense, to act in your name and on your behalf to negotiate, defend or settle, as we see fit, any liability you are facing. Subrogation After we have accepted a claim either in whole or in part, we shall be fully subrogated to your position and shall be able to exercise for our own benefit any legal right of recovery held by you. You shall, at our expense, fully co-operate in the enforcement of this right by the company. You shall not release any third party from liability that could arise from loss covered by this policy, unless agreed to by us. Disputes The law of New Zealand shall apply to any dispute about this policy and the New Zealand Courts shall have exclusive jurisdiction. general conditions applicable to all parts of the policy One Contract This policy wording and the schedule and any endorsements shall be read together as one contract. The Application and other information submitted shall be incorporated in the contract. Observance It shall be a condition precedent to our liability under this policy that: a. you have complied with all the terms of the policy; and b. the statements and answers in the: i Application; and ii any Claim Form; and iii any notice of change in circumstance or given separately in support of any of them (whether by any one of the insured or any other person), are true and correct; and c. if the policy covers the interests of any person other than the insured, that person also complies with the same terms and conditions of the policy where applicable. Insurance Law Reform Acts The conditions and exclusions in this policy are subject to your rights set out in the Insurance Law Reform Acts. Change in Circumstance a. You shall give immediate written notice to us of any change in circumstance since inception of the policy which materially increases the risk of a claim. 9

AMI Businesspack Business Insurance Policy wording Welcome, thanks for choosing to protect your business with IAG New Zealand Limited. AMI Insurance Limited is part of the IAG group of companies in New

Contract Works Policy FMG has been protecting the property and livelihoods of people up and down the country since 1905. We re 100% New Zealand owned and operated and are proud to be the country s only

Schedule 15A: Insurance Part 1 Required Insurances Sub-part 1 Design and Construction Phase The policies to be taken out by the Contractor, or caused to be taken out by the Major Sub-contractor, and maintained

CONTRACTORS ALL RISKS INSURANCE POLICY WHEREAS THE INSURED named in the Schedule hereto has made to Cumberland Insurance & Reinsurance Company Limited (hereinafter called "the Insurers") a written proposal

Policy Wording Professional Indemnity Insurance Issued to Eligible Emergency Resource Providers by VMIA For the period date 30 June 2015 to 30 June 2016 Contents Professional Indemnity Policy... 3 Definitions...

Employers Liability Insurance Policy You only have cover under this policy if the schedule lists it as included. This policy should be read in conjunction with the schedule. Contents 1 Definitions... 2

Policy Wording Directors and Officers Liability and Company Reimbursement Issued to Eligible Emergency Resource Providers by VMIA For the period date 30 June 2014 to 30 June 2015 Contents Directors and

OnSiteTM Annual Declaration contract works policy ENO32 Every Lumley product comes with expert advice and service. This policy document is backed by our Construction and Engineering team. With their combined

CARRIER S TRANSIT LIABILITY INSURANCE POLICY INSURANCE AGREEMENT OUR AGREEMENT You agree to pay us the premium. In exchange, we agree to insure you as set out in this policy document. WHAT YOU ARE INSURED

Section 3E Public and Product Liability - General Definitions Business The business stated in the specification to this section and includes: a) the provision and management of canteen, sports, social,

Contractors All Risks Policy Whereas the Insured named in the Schedule hereto has made to the Etiqa Insurance Pte. Ltd. (hereinafter called the Company ) a written proposal by completing a Questionnaire

HOME WARRANTY Insurance Policy [VICTORIA] In consideration of the payment by the Builder of the premiums specified in the Schedule to this policy, the Insurer will provide insurance cover to the Building

Business Insurance Business equipment section Contents of this section Meaning of defined terms 1 What is covered 3 What is not covered 4 Section conditions 6 Meanings of defined terms These meanings apply

Contractors Plant and Equipment Insurance Policy Please read this Policy carefully to ensure that it meets your requirements This policy the Schedule (including any Schedule issued in substitution) and

ACN 002 566 743 Brookvale Insurance Brokers Pty Ltd Contract Works and What you need to Know 1. The Need for Contract Works Insurance The growth of large-scale construction projects has been accompanied

Insurance CONTRACTORS ALL RISKS POLICY Whereas the Insured named in the Schedule hereto has made to the ETIQA INSURANCE BERHAD (hereinafter called the Company ) a written proposal by completing a Questionnaire

Contract Works Insurance Policy This is your Westpac Contract Works Insurance policy. It is an important document and should be kept in a safe place. Please take time to read this document. Table of Contents

PUBLIC LIABILITY INSURANCE POLICY IT IS AGREED THAT subject to the Terms Exceptions and Conditions contained herein or endorsed hereon the Company will during the Period of Insurance stated in the said

ARIEL AIRPORT OWNERS AND OPERATORS LIABILITY INSURANCE The Insurers hereby agree to the extent and in the manner hereinafter provided, to pay on behalf of the Insured all sums which the Insured shall become

Policy Whereas the Insured named in the Schedule hereto has made to the (hereinafter called the Insurers ) a written proposal by completing a questionnaire which together with any other statements made

CONTRACTORS ALL RISKS INSURANCE POLICY WHEREAS the Insured named in the Schedule by a proposal and declaration which shall be the basis of this contract and is deemed to be incorporated herein has applied

Landlord Protection Policy ... students or working professionals? Some decisions in life are hard. Stylecover is the easy choice. Aon / New Zealand s Largest Insurance Broker 0800 50 51 52 Money back guarantee

MOTOR TRADE INSURANCE POLICY WHEREAS the Insured by a proposal and declaration which shall be the basis of this contract and is deemed to be incorporated herein has applied to the Company for the insurance

Medical Malpractice Insurance Policy You only have cover under this policy if the schedule lists it as included. This policy should be read in conjunction with the schedule. Contents 1 Definitions... 2

Marine household goods & personal effects transit INSURANCE POLICY INSURANCE AGREEMENT OUR AGREEMENT You agree to pay us the premium. In exchange, we agree to insure you as set out in this policy document.

1 2 Name of Proposer (in full) Address PROPOSAL FORM FOR CONTRACTORS ALL RISKS INSURANCE 3 4 Trade or business Name and address of Principal for whom contract is to be undertaken 5 6 7 Description of Contract.

AMP Site Cover Policy Document Welcome Thank you for choosing us to provide you with your insurance cover. Arranging insurance means you are making a legal contract under which you promise to meet certain

Commercial Insurance section Defined events Damages which the insured shall become legally liable to pay consequent upon accidental death of or bodily injury to or illness of any person (hereinafter termed

CONTRACTOR'S ALL RISKS INSURANCE POLICY WORDING 1 CONTRACTOR'S ALL RISKS INSURANCE POLICY WHEREAS the insured named in the schedule hereto had made to Magma HDI General Insurance Co. Ltd. (here in after

PROFESSIONAL INDEMNITY INSURANCE FOR POLICY WORDING OUR PROMISE TO YOU In return for the premium you have paid, we agree to insure you in accordance with the terms and conditions of this policy. Signed

PUBLIC LIABILITY INSURANCE This Policy does not provide insurance for Products or goods supplied in the course of the Insured s principal business activity. RoyalStar Assurance Ltd. P. O. Box N-4391 P.

INDIA MOTOR TARIFF w.e.f 01.07.2002 - Policy wording STANDARD POLICY FORM FOR MOTOR TRADE INTERNAL RISKS Whereas the insured by a proposal and declaration dated as stated in the Schedule which shall be

Reg.No.1918/001680/06 SANTAM BPK/LTD Professional Indemnity Insurance Group & Personal Trainers Scheme Administered by LSG Insurance Services This is to certify that in accordance with the authorization

MATERIAL DAMAGE AND BUSINESS INTERRUPTION INSURANCE SUGGESTED WORDINGS Competition Law Compliance: This document has been produced by the ABI to assist members in their handling of a particular matter.

Optima Blocks of flats (all risks) This document is a guide to the cover provided under your Optima Blocks of Flats (All Risks) policy. It is only a summary and does not contain the full terms and conditions

Ministerial Insurance Order - Required Insurance for Accredited Building Practitioners 2008 approved on 15 July 2008. Published in the Tasmanian Government Gazette on 30 July 2008 and effective 30 August

General Liability Insurance Insurance Company: Alberta School Boards Insurance Exchange (ASBIE) Insuring Agreement ASBIE agrees to pay on behalf of the Subscriber all sums that they are legally obligated

Business Insurance Professional indemnity section for recruitment professionals Contents of this section Important information about this cover 1 Meaning of defined terms 2 What is covered 4 What is not

Tradesman Essential Per Capita Liability Insurance www.towergate.co.uk This leaflet provides a summary of the significant features, benefits and limitations of the cover provided by your Tradesman Essentials

General Insurance AMP Landlord Plan Policy June 2010 Landlord Plan Policy Document Thank you for choosing us to provide you with your insurance cover. Arranging insurance means you are making a legal contract

Contractors all risks policy No. Whereas the Insured named in the Schedule hereto has made to the (hereinafter called the Insurers ) a written proposal by completing a questionnaire which together with

Carhood & Insuret Hire Fleet Insurance Product Disclosure Statement 1 This Product Disclosure Statement (PDS) has been in use since 1st July 2012. The IMPORTANT INFORMATION section summarises the significant

Allianz Insurance plc Construction Project All Risks Product Information This information is for intermediaries only Construction Project All Risks Insurance Policy Wherever there is the construction of

AMI Businesspack Business Insurance Policy wording Welcome, thanks for choosing to protect your business with IAG New Zealand Limited. AMI Insurance Limited is part of the IAG group of companies in New

PRIORITY Professional Indemnity Insurance Contract Between AC&E PI and Liability Underwriters (Pty) Ltd acting as underwriting managers on behalf of the New National Assurance Company Ltd and hereafter

SPECIMEN COPY OF KEY CLAUSES/CONDITIONS OF PUBLIC LIABILITY POLICY Appendix 7b 1 WHEREAS the Insured by a proposal which shall be the basis of this Contract and be held as incorporated herein has applied

Policy of Insurance under the HBCF (Home Building Compensation Fund) How to read the policy (i) The policy covers you for the types of loss, and for the amounts of loss, described in clause 1. (ii) Clause

General Liability Policy Nuku alofa: Patco Building, Taufa ahau Road Phone: (676) 21105 Fax: (676) 25143 We would like to make sure You are aware of all Your entitlements under this policy, so please read

CANOPIUS UNDERWRITING LTD PROFESSIONAL INDEMNITY INSURANCE POLICY FOR DESIGN AND CONSTRUCTION Various words and phrases have a standard meaning within this policy of insurance and such meanings are defined