Calhoun County, Florida hereby provides notice, pursuant to section 197.3632(3)(a), Florida Statutes, of its intent to use the uniform method of collecting non-ad valorem special assessments to be levied within the County, for the cost of providing solid waste services commencing for the Fiscal Year beginning on October 1, 2010 and continuing until discontinued by the County. The County will consider the adoption of a resolution electing to use the uniform method of collecting such assessments authorized by section 197.3632, Florida Statutes, at a public hearing to be held at 5:00 p.m. on February 16, 2010 at the Commission Chamber, 20816 Central Avenue E., Blountstown, FL 32424. Such resolution will state the need for the levy and will contain a legal description of the boundaries of the real property subject to the levy. Copies of the proposed form of resolution, which contains the legal description of the real property subject to the levy, are on file at the Clerk’s Office, 20859 Central Avenue E., Room 130 Blountstown, FL 32424. All interested persons are invited to attend.
In the event any person decides to appeal any decision by the County with respect to any matter relating to the consideration of the resolution at the above-referenced public hearing, a record of the proceeding may be needed and in such an event, such person may need to ensure that a verbatim record of the public hearing is made, which record includes the testimony and evidence on which the appeal is to be based. In accordance with the Americans with Disabilities Act, persons needing a special accommodation or an interpreter to participate in this proceeding should contact the County Clerk at 850-674-4545 two (2) days prior to the date of the hearing.
DATE this 19th day of January 2010.

By Order of Dan Wyrick
CALHOUN COUNTY, FLORIDA

Legal Notice

NOTICE TO RECEIVE SEALED BIDS

The Town of Altha will receive sealed bids from any qualified person, company or corporation interested in providing construction services for the following project:

This project will include the installation of approximately 16,685± LF of 6” PVC watermain throughout the Town of Altha, 24 fire hydrants, 37 gate valves, re-connection of approximately 123 service connections, directional boring and minor asphalt repairs. Removal of trees within the project limits inside the right of way is also included.

Completion date for this project will be 150 days from the date of the Notice to Proceed presented to the successful bidder.

Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.

Please indicate on the envelope that this is a sealed bid, for the “Altha Water System Improvements – Phase II”.

Bids will be received until 2:00 p.m. Central Time, on February 23, 2010, at the Altha Town Hall, 25586 North Main Street, Altha, Florida 32421, and will be opened and read aloud on February 23, 2010 at 3:00 p.m. Central Time. The public is invited to attend. The Town of Altha is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.

Proof of Florida Department of Transportation current certificate of qualification in the following work categories is required: Grading, Drainage, Grassing, Seeding and Sodding, Flexible Paving and Hot Plant Mix Bituminous. Primary contractor shall be qualified in a minimum of: Grading, Drainage, Grassing, Seeding and Sodding.

Cost for Plans and Specifications will be $200.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.

A Pre-Bid Conference shall be held at the Altha Town Hall, at 9:00 pm Central Time, February 10, 2010. Please call Kristin Brown at (850) 643-2771 with any questions.

The Town of Altha reserves the right to reject any and all bids. All Bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.

Legal Notice

R & R WAREHOUSES
NOTICE OF SALE

On February 8, 2010, at 10:00 a.m. (CST), R & R Warehouses will dispose of the contents of seven (7) storage units from Blountstown and five (5) storage unit from Bristol at 19300 SR 20 W. (850) 674-4700.
The units are believed to contain household and/or personal property of the following tenants:

This project will include the installation of approximately 16,685± LF of 6” PVC watermain throughout the Town of Altha, 24 fire hydrants, 37 gate valves, re-connection of approximately 123 service connections, directional boring, re-grading of ditches and minor asphalt repairs. Removal of trees within the project limits inside the right of way is also included.

Completion date for this project will be 150 days from the date of the Notice to Proceed presented to the successful bidder.

Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.

Please indicate on the envelope that this is a sealed bid, for the “Altha Water System Improvements – Phase II”.

Bids will be received until 2:00 p.m. Central Time, on February 23, 2010, at the Altha Town Hall, 25586 North Main Street, Altha, Florida 32421, and will be opened and read aloud on February 23, 2010 at 3:00 p.m. Central Time. The public is invited to attend. The Town of Altha is an Equal Opportunity Employer/Handicapped Accessible/Fair Housing Jurisdiction.

Proof of Florida Department of Transportation current certificate of qualification in the following work categories is required: Grading, Drainage, Grassing, Seeding and Sodding, Flexible Paving and Hot Plant Mix Bituminous. Primary contractor shall be qualified in a minimum of: Grading, Drainage, Grassing, Seeding and Sodding.

Cost for Plans and Specifications will be $100.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.

A Pre-Bid Conference shall be held at the Altha Town Hall, at 9:00 a.m. Central Time, February 10, 2010. Please call Kristin Brown at (850) 643-2771 with any questions.

The Town of Altha reserves the right to reject any and all bids. All Bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.

Legal Notice

PUBLIC AUCTION

Mallory Towing and Recovery Inc. will hold a public auction on, February, 16, 2010 at 2:00 (P.M.) on a:

1982 Ford, SW, Gray in Color
Vin#1FMEU15F0CLA07171

1994 Pontiac, 4 Door, Red in Color
Vin#1G2WJ52M6RF229933

Auction will be held at Mallory Towing and Recovery Inc. at 18114 State Road 20 West in Blountstown FL., 850-674-2869.

Mallory Towing and Recovery Inc. reserves the right to reject any and all bids.

Legal Notice
NOTICE OF PUBLIC HEARING

NOTICE IS HEREBY GIVEN that the Board of County Commissioners in and for Calhoun County, Florida, will consider a proposed Ordinance to be titled as follows:
AN ORDINANCE OF THE COUNTY COMMISSION OF CALHOUN COUNTY, FLORIDA; RELATING TO THE PROVISION OF MANDATORY RESIDENTIAL SOLID WASTE COLLECTION SERVICES THROUGH THE USE OF SERVICE AGREEMENTS WITH INDEPENDENT CONTRACTORS; PROVIDING CERTAIN DEFINITIONS AND LEGISLATIVE FINDINGS; AUTHORIZING THE APPROVAL OF SERVICE AGREEMENTS WITH INDEPENDENT CONTRACTORS; PROVIDING FOR MANDATORY RESIDENTIAL SOLID WASTE COLLECTION; PROVIDING THE RESPONSIBILITIES OF RESIDENTIAL PROPERTY OWNERS AND OCCUPANTS; PROHIBITING THE UNAUTHORIZED COLLECTION OR DISPOSAL OF SOLID WASTE; PROVIDING CERTAIN EXEMPTIONS; PROVIDING FOR TREATMENT OF A PUBLIC NUISANCES; PROVIDING PROCEDURE FOR ENFORCEMENT; PROVIDING THAT PROCEDURES IN ORDINANCE ARE SUPPLEMENTAL AUTHORITY; PROVIDING FOR SEVERABILITY; AND PROVIDING AN EFFECTIVE DATE.

The passage of the proposed Ordinance will be considered by the Board of County Commissioners, at their regular meeting at 5:05 P. M., C.S.T., on Tuesday, the 16th day of February, 2010, at the County Commission Boardroom, in the Courthouse Annex, Blountstown, Florida.
A copy of the proposed Ordinance can be inspected by the public at the County Commissioners’ Office in the Calhoun County Courthouse.
All interested parties may appear at the meeting and be heard with respect to the proposed Ordinance.
WITNESS my Hand and Official Seal, this the 2nd day of February, 2010.