Public Notices

ADVERTISEMENT FOR BIDS Sealed proposals will be received by The Alabama Department of Agriculture and Industries at the office of Department of Agriculture and Industries Richard Beard Building, 14...

ADVERTISEMENT FOR BIDS Sealed proposals will be received by The Alabama Department of Agriculture and Industries at the office of Department of Agriculture and Industries Richard Beard Building, 1445 Federal Drive, Montgomery, Alabama 36107, until 2:00 pm CST August 28, 2018, for Roofing and Alterations of the State Farmers Market Buildings, 1655 Federal Drive, Montgomery, AL 36107 at which time and place they will be publicly opened and read. A cashier's check or bid bond payable to The Alabama Department of Agriculture and Industries in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract. Drawings and Specifications may be examined at the Office of the Architect; McGraw-Hill Dodge Plan Room; AL AGC/iSqFt Plan Room and Reed Construction Data. Electronic images of bid documents may be viewed online for a deposit of $0.00 through the Architect's online planroom at www.sslarch.com by accessing the Info Exchange Login. For access to plans via this website, email Davis Campbell: dcampbell@sslarch.com or call Seay, Seay & Litchfield at (334) 263-5162. These documents may be used only for the purpose of bidding and constructing this project. Anyone logging into the site for plans and specifications through the web site will be notified of all addenda by e-mail. The architect retains all copyrights and ownership of the documents. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted. There will be a non-mandatory pre-bid conference. All bidders are invited to attend on Tuesday, August 21, 2018 at 10:00 a.m. at the State Farmers Market Complex, 1655 Federal Drive, Montgomery, AL 36107. The Alabama Department of Agriculture and Industries (Awarding Authority) The Alabama Department of Agriculture and Industries (Local Awarding Authority) Seay, Seay & Litchfield, P.C. (Architect) Mont. Adv. 8/12, 8/19, 8/26/2018 3095011

ADVERTISEMENT FOR BIDS Sealed proposals will be received by the Alabama Department of Transportation at the office of the Alabama Department of Transportation located at 299 Elba Highway, Troy, AL 3...

ADVERTISEMENT FOR BIDS Sealed proposals will be received by the Alabama Department of Transportation at the office of the Alabama Department of Transportation located at 299 Elba Highway, Troy, AL 36081, until 2:00 p.m. Local Time Thursday, September 13, 2018 for "A New Shop for ALDOT Southeast Region District 76, Eufaula, AL", at which time and place they will be publicly opened and read. Bidders are responsible for assuring their bids are received prior to bid date and time. The general scope of work includes Site work and septic system for a new 6,800 square foot pre-engineered metal building with office, restrooms with showers, storage, loft storage, plumbing, mechanical, electrical systems, 200 KW emergency generator and site electrical service upgrades. All bids must be submitted in a sealed envelope bearing on the outside the name of the Bidder, Bidder's license number, and name of the project. Envelopes containing bids must be addressed as follows, and delivered to The Alabama Department of Transportation, Attention: Mr. Matthew D. Wilson, P.O. Box 647, Troy, AL 36081: "A NEW SHOP FOR ALDOT SOUTHEAST REGION DISTRICT 76, Eufaula, AL". A cashier's check or bid bond payable to the Alabama Department of Transportation in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Contractor can purchase plans and specifications from Quality Blue Print L.L.C. (334)262-9344 at reproduction cost plus shipping/ handling. Drawings and specifications may be examined at the offices of Robinson and Associates Architecture, Inc., 906 South Perry Street, Montgomery, Alabama 36104; I-Square-Foot Plan Room in association with Associated General Contractors; Reed Construction Data at www.reedconstructiondata.com. All bids must be based upon the Drawings, Specifications, Clarifications and Addenda. A Mandatory Pre-Bid Conference will be held at 2:00 p.m. Local Time Tuesday, August 28, 2018 at the Alabama Department of Transportation, 760 Hwy 30, Eufaula, AL 36027. Bids must be submitted on proposal forms furnished by ALDOT or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted. No bidder may withdraw his bid within 45 days after the actual date of the opening thereof. Nonresident bidders must accompany any written bid documents with a written option of an attorney at law licensed to practice law in such nonresident bidder's state of domicile, as to the preferences, if any or none, granted by the law of that state to its own business entities whose principal places of business are in that state in the letting of any or all public contracts. John R. Cooper, Director The Alabama Department of Transportation (Awarding Authority) Mont. Adv. 8/5, 8/12, 8/19/2018 3070615

ADVERTISEMENT FOR BIDS REROOFING VARIOUS BUILDINGS FOR ALABAMA STATE UNIVERSITY MONTGOMERY, ALABAMA PROJECT NO. 18-176 ASU BID NO. 3016-2018 Alabama State University shall accept proposals from Contractors who have successfully completed at least 3 similar projects on time for satisfied State, County or City Governmental Agencies. The lowest responsible bidder shall submit to the Architect within 24 hours after submitting their bid proposal a listing of projects, construction cost, Owners address and telephone numbers. Alabama State University seeks to encourage and facilitate greater participation by minority business enterprises in contracts for construction and for the purchase of goods, materials, equipment, or services. For the purposes hereof "minority business" means any business enterprise, whether individually owned, or a partnership, joint venture, or corporation, which is wholly or substantially owned or controlled by black persons or members of some other racial or national minority group, and/or women. A pre-bid walk-thru shall be held on site on Wednesday, August 15, 2018 at 9:00 AM, starting at the Music Building. The sealed proposals should show ASU Bid # 3016-2018- DO NOT OPEN on the outside of Bid Envelope. The sealed proposal shall be received by Arlene P. Thompson, Director of Contracts and Acquisitions/Procurement Department, Alabama State University Procurement Department, 1301 West 5th Street, Suite 104, Montgomery, Alabama, until 2:00 PM, Thursday, August 23, 2018, then opened and read aloud. The project shall be bid excluding taxes. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. No bid may be withdrawn after scheduled closing for receipt of bids for a period of sixty (60) days. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owners judgment, the best interests of the Owner will thereby be promoted. A certified check or Bid Bond payable to Alabama State University in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000.00 must accompany the bidder's proposal. Performance and statutory labor and material payment bonds will be required at the signing of the Contract. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect. All bidders shall show such evidence by clearly displaying current license number on the outside of the sealed envelope in which the proposal is delivered. Electronic images of the documents may be viewed on-line and printed by General Contractors, Sub Contractors and Suppliers by obtaining documents through the www.mckeeassoc.com web site, by contacting the Architect at mckeeplans@gmail.com for log-in information and password. Please provide company name, address, phone #, fax #, email address and GC License #. This is the only web site endorsed by the Architect. The Architect is unable to monitor, confirm and maintain websites that are beyond his control. Addendums shall be posted on the above web site. The Architect retains ownership and copyrights of the documents. If bidders require printed sets the following shall apply: Submit to the Architect a deposit of $50.00 per set. The deposit shall be refunded less shipping charges for each set returned in reusable condition within ten days after bid opening. All RFI's and RFA's regarding the bid documents shall be sent and addressed thru the following e-mail account: singletonk@mckeeassoc.com. The Architect will not accept inquires via telephone or fax. Completion Time: All work shall be completed in 60 calendar days from the "Notice To Proceed". Supervision: Contractor to provide Superintendent(s) to ensure proper supervision for all work. Owner: Mr. Donald Dotson, Vice-President of Facilities and Operations Alabama State University 1301 West 5th Street, Suite 104 Montgomery, Alabama 36104 Program Manager: Mr. Tommy Lawrence TCU Consulting Services 2895 Eastern Blvd., Suite 150 Montgomery, AL 36116 Tel: (334) 420-1500 Architect: McKee and Associates Architecture and Interior Design 631 South Hull Street Montgomery, Alabama 36104 Phone: (334) 834-9933 Mont. Adv. 8/3, 8/10, 8/17/2018 3073338

ADVERTISEMENT FOR BIDS Sealed proposals will be received by Troy University by the Purchasing Department of Troy University, at Everett Hall Conference Room, located on University Drive, Dothan, Alab...

ADVERTISEMENT FOR BIDS Sealed proposals will be received by Troy University by the Purchasing Department of Troy University, at Everett Hall Conference Room, located on University Drive, Dothan, Alabama 36303 until 2:00 PM CST for the base bids and all alternates on Thursday, September 6th, 2018 at which time they will be open and read. Troy University Coleman Hall, 500 University Drive, Troy University Dothan Campus - Dothan, Alabama. A cashier's check or bid bond payable to Troy University in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract. Drawings and specifications may be examined at the Office of the Architect; Dodge Data & Analytics and Construct Connect. Electronic images of bid documents may be viewed online for a deposit of $0.00 through the Architect's online planroom at www.sslarch.com by accessing the Info Exchange Login. Questions pertaining to accessing the website should be directed to Seay, Seay & Litchfield at rprice@sslarch.com (334) 791-5248. These documents may be used only for the purpose of bidding and constructing this project. Anyone logging into the site for plans and specifications through the website will be notified of all addenda by e- mail. The architect retains all copyrights and ownership of the documents. Bids must be submitted on proposal forms furnished by the Architect (Engineer) or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect (Engineer); the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted. A pre-bid meeting will be held in the conference room at Everett Hall on Troy's Dothan Campus-Dothan, AL 36303, at 2:00 PM CST on the date of Tuesday, August 21st 2018. Owner: Architect: Troy University Seay, Seay & Litchfield, P.C. Jessica Hasson 2431 W. Main Street - Suite 101 211 Wright Hall Dothan, AL 36301 Troy Alabama 36082 (334) 791-5248 (334) 670-3128 bids@troy.edu Mont. Adv. 8/5, 8/12, 8/19/2018 3077036

ADVERTISEMENT FOR BIDS For Community Development Institute Head Start Serving Chilton, Autauga, Shelby, and Elmore Counties, AL Requirements for Bidding: Community Development Institute Head Start S...

ADVERTISEMENT FOR BIDS For Community Development Institute Head Start Serving Chilton, Autauga, Shelby, and Elmore Counties, AL Requirements for Bidding: Community Development Institute Head Start Serving Chilton, Autauga, Shelby, and Elmore Counties, AL (CDI HS) shall accept proposals from Contractors who have successfully completed at least 3 similar projects of size, scope, and on time or have previous project experience with the Owner or Architect. This requirement only applies to the New Head Start Facility for Queen Ann Road, Wetumpka, Alabama (#18-116A) as referenced below. Separate sealed proposals will be received for the below referenced projects at the Office of McKee and Associates, Architects, 631 South Hull Street Montgomery, Alabama 36104, at the times stated below, then opened and read aloud. New Head Start Facility for Queen Ann Road, Wetumpka, Alabama (#18-116A) will bid on Tuesday, August 28, 2018, at 2:00 PM. All work shall be completed in 240 calendar days from the "Notice To Proceed". Alterations To Robinson Springs Head Start, Millbrook, Alabama (#18-116C) will bid on Friday, September 7, 2018, at 2:00 PM. A non-mandatory pre-bid conference to be held at the site located at 5720 Main Street, Millbrook, AL., 36054 on Wednesday, August 22, 2018 at 2:00 PM. General Contractors bidding this project shall be required to visit the site and examine all existing conditions prior to submitting their proposal. All work shall be completed in 180 calendar days from the "Notice To Proceed". Current Davis Bacon Wage Rates shall apply to these projects. All Bidders shall have general liability and workman's compensation insurance. All contractors, sub-contractors, vendors, etc., performing work on the project, shall have a current business license with the City of project locations. CDI HS is an equal opportunity employer. Bids must be submitted on separate proposal forms furnished by the Architect or copies thereof. No bid may be withdrawn after scheduled closing for receipt of bids for a period of sixty (60) days. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owners judgment, the best interests of the Owner will thereby be promoted. A separate certified check or Bid Bond for each project payable to Community Development Institute Head Start Serving Chilton, Autauga, Shelby, and Elmore Counties, AL in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000.00 must accompany the bidder's proposal. Performance and statutory labor and material payment bonds will be required at the signing of the Contract. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect. All bidders shall show such evidence by clearly displaying current license number on the outside of the sealed envelope in which the proposal is delivered. Electronic images of the documents may be viewed on-line and printed by General Contractors, Sub Contractors and Suppliers by obtaining documents through the www.mckeeassoc.com web site, by contacting the Architect at mckeeplans@gmail.com for log-in information and password. Please provide company name, address, phone #, fax #, email address and GC License #. This is the only web site endorsed by the Architect. The Architect is unable to monitor, confirm and maintain websites that are beyond his control. Addendums shall be posted on the above web site. The Architect retains ownership and copyrights of the documents. If bidders require printed sets the following shall apply: Submit to the Architect a deposit of $150.00 per set. The deposit shall be refunded for each set returned in reusable condition within ten days after bid opening. All RFI's and RFA's regarding the bid documents shall be sent and addressed thru the following e-mail account: woodhamw@mckeeassoc.com. The Architect will not accept inquires via telephone or fax. Owner: Community Development Institute Head Start Serving Chilton, Autauga, Shelby, and Elmore Counties, AL Architect: McKee and Associates Architecture and Interior Design 631 South Hull Street Montgomery, Alabama 36104 Phone: (334) 834-9933 Mont. Adv. 8/10, 8/17, 8/24/2018 3090917

ADVERTISEMENT FOR COMPLETION LEGAL NOTICE In accordance with Chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that Outdoor Aluminum, Inc., Contractor, has completed the Contract f...

ADVERTISEMENT FOR COMPLETION LEGAL NOTICE In accordance with Chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that Outdoor Aluminum, Inc., Contractor, has completed the Contract for Bleacher Replacement and Press Box Phase 3 to Billingsley School, Billingsley, Alabama, for the State of Alabama and the Autauga County Board of Education of Prattville, Alabama, Owners, and has made request for final settlement of said Contract. All persons having any claim for labor, materials, or otherwise in connection with this project should immediately notify: Wible Berber Architects, LLC 529 South Perry Street, Suite 16 Montgomery, AL 36104 Outdoor Aluminum, Inc. P.O. Box 118 Geneva, AL 36340 Mont. Adv. 8/1, 8/8, 8/15, 8/22/2018 3066974

Advertisement for Prequalification of Contractors and for Bids from Bidders that are Prequalified Prequalification Proposals (Letters of Interest (LOI) and Statements of Qualifications (SOQ)) from ...

Advertisement for Prequalification of Contractors and for Bids from Bidders that are Prequalified Prequalification Proposals (Letters of Interest (LOI) and Statements of Qualifications (SOQ)) from General Contractors (Construction Service Firms) shall be submitted and will be received by the Board of Water and Sewer Commissioners of the City of Mobile, Alabama ("Board"), at the Wesley A. James Operations Center, 4725 Moffett Road, Suite A, Mobile, AL 36618-0249; UNTIL 2:00 PM, LOCAL TIME, SEPTEMBER 4, 2018, for the following project: Contract No. 160039, THREE MILE CREEK TRUNK SEWER UPGRADES, GMC Project No. CMOB160039 for consideration of approval to bid this project. Prequalified Bidders will be notified in writing on or about September 10, 2018, at which time Bid and Construction Documents will be made available to bidders. Instructions for SOQ packages may be inspected at the Board's offices at 4725 Moffett Road, Suite A, Mobile, AL, or requested at the offices of Goodwyn, Mills and Cawood, Inc., Consulting Engineers, 11 North Water Street, Suite 15250, Mobile, AL 36602 Attn: Ashley Morris 251.460.4006 ashley.morris@gmcnetwork.com. For the list of plan qualification request holders on this project visit http://www.gmcnetwork.com. Scroll to the bottom of the page and click on Project Bids. As one of the conditions of submitting a SOQ, it must be understood that knowledge and experience is extremely important. Therefore, the construction firm will have to submit evidence and proof acceptable to the Board of their ability, knowledge, experience, training of supervisory personnel and labor, and will be required to submit evidence and proof that construction firm has performed work of a similar nature within the last twenty-four (24) months and that such work was satisfactorily and safely completed. Qualifications of any sub-contractor(s) used to obtain prequalification status are to be included in the firm's statement of qualifications. Contractors should pay special attention to the Board's Supplier Diversity Program requirements to ensure prequalification packages include the required documentation as to participation of diverse sub-contractor(s) and suppliers to meet the Board's goals of the Contractor's good faith efforts to secure such participation. The Owner reserves the right to reject any or all proposals, to waive technical errors, and/or abandon this process if, in their judgment, the best interests of the Owner will thereby be promoted. All General contractors seeking prequalification status are required to submit the prequalification documents enclosed and clearly marked on the outside of the package as follows: "CONFIDENTIAL STATEMENT OF QUALIFICATIONS THREE MILE CREEK TRUNK SEWER UPGRADES," Board of Water and Sewer Commissioners of the City of Mobile, Alabama ATTN: Douglas L. Cote, PE, Assistant Director of Operations, 4725 Moffett Road, Suite A, Mobile, AL 36618-0249. Sealed bid proposals will be received only from Prequalified General Contractor Bidders by the Board of Water and Sewer Commissioners of the City of Mobile, Alabama ("Board"), at the Wesley A. James Operations Center, 4725 Moffett Road, Suite A, Mobile, AL 36618-0249; UNTIL 12:30 PM LOCAL TIME; ON MONDAY, OCTOBER 8, 2018, at which time and place they will be publicly opened and read. The Work of the project includes, but is not limited to the following: The construction of approximately eleven thousand (11,000) linear feet of sixty inch (60") gravity trunk sewer main and manholes, reconnection of existing branch mains to the new trunk sewer, three (3) double barrel depressed sewers, including one crossing of Three Mile Creek, 96" steel casing installation at roadway crossings, and all related appurtenances. The project is located on the south side of Three Mile Creek just north of Mobile Street, continues on the south side of the creek until a crossing just west of Stanton Road, and remains on the north side of Three Mile Creek until the tie-in to the new diversion box (by others) at the Board's Severe Weather Attenuation Tank (SWAT) west of St. Stephen's Road. Copies of the Bidding Documents may be obtained from the Consulting Engineer, upon payment of $20.00 for a one time administrative fee for digital/file sharing access or $200.00 for each (printed) set. Contractors are encouraged to use the digital plans. Said cost represents the cost of printing, reproduction, handling, and distribution, therefore no refund will be granted. Checks shall be made payable to "Goodwyn, Mills & Cawood, Inc." Bid documents will be mailed only upon receipt of deposit. No Contract Documents will be issued later than twenty-four (24) hours prior to bid submission time. Refer to MAWSS Policy No. DBE 16-01 Disadvantaged Business Enterprise Policy for Public Works Act Contracts, which states that contractors shall make a demonstrated good faith effort to award fifteen percent (15%) of the contract amount to certified Disadvantaged Business Enterprises as subcontractors and/or suppliers performing commercially useful functions which are consistent with contract requirements. Further information for requirements during the bidding and contract performance phases are provided in Policy No. DBE 16-01 and should be considered by prospective bidders. Also, bidders must list all DBE subcontractors and suppliers on the provided Subcontracting Plan form to be submitted with the package. A Pre-Bid Conference will be held at the MAWSS Main Training Room at the Park Forest Facility, 4725A Moffett Road, Mobile, AL 36618 on Thursday, September 27, 2018 at 10:00 A.M. Local Time, to discuss bidding and project requirements. Prospective prequalified bidders and subcontractors are required to attend. Bids must be submitted on the standard forms included with the Contract Documents. The following contract bid documents, Bid Proposal, Bid Bond, Subcontracting Plan, SSO and Unpermitted Discharge Prevention Notification, and any addendum attachments shall be printed on yellow color paper and tabbed. The Contractor shall be responsible for preparing its bid package in accordance with this guideline. Envelopes containing bids must be sealed and delivered to the Director, Board of Water and Sewer Commissioners of the City of Mobile, Alabama, 4725A Moffett Road, Mobile, Alabama 36618-0249: "Bid for Constructing Contract No. 160039, Three Mile Creek Trunk Sewer Upgrades, GMC Project No. CMOB160039, to be opened at 12:30 p.m., Local Time, October 8, 2018". The Bidder's Alabama State Contractor's License Number and discipline shall be on the envelope. Bid guarantee in the form of certified check, bid bond, or Irrevocable Letter of Credit acceptable to the Board will be required for at least 5% of the bid amount, not to exceed $50,000. The Board reserves the right to reject any and all bids and to waive any informality in bids received. THIS INVITATION FOR PREQUALIFICATION OF CONTRACTORS AND FOR BIDS FROM BIDDERS THAT ARE PREQUALIFIED IS CONDENSED FOR ADVERTISING PURPOSES. ADDITIONAL INFORMATION/REQUIREMENTS FOR BIDDERS CAN BE FOUND IN THE CONTRACT DOCUMENTS. THE BOARD OF WATER AND SEWER COMMISSIONERS OF THE CITY OF MOBILE, ALABAMA Mont. Adv. 8/14/2018 3098471

FORM OF ADVERTISEMENT FOR COMPLETION LEGAL NOTICE In accordance with Chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that Rolin Construction Inc. Contractor, has completed the Con...

FORM OF ADVERTISEMENT FOR COMPLETION LEGAL NOTICE In accordance with Chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that Rolin Construction Inc. Contractor, has completed the Contract for Counstruction of a New Archery Range at Wetumpka Sports Complex for the State of Alabama and the County of Montgomery, Owner(s), and have made request for final settlement of said Contract. All persons having any claim for labor, materials, or otherwise in connection with this project should immediately notify Department of Conservation (Engineering) (Architect) Rolin Construction Inc. (Contractor) 5060 Jack Springs Road Atmore, AL 36502 Mont. Adv. 8/4, 8/11, 8/18, 8/25/2018 3075733

FORM OF ADVERTISEMENT FOR COMPLETION LEGAL NOTICE In accordance with Chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that Contractor, has completed the Contract for Renovation of V...

FORM OF ADVERTISEMENT FOR COMPLETION LEGAL NOTICE In accordance with Chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that Contractor, has completed the Contract for Renovation of VCT Flooring Installation at Daniel Pratt Elementary Autaugaville School and the Autauga County Tech Center at Autaugaville County for the State of Alabama and the (County) (City) of Autaugaville/Prattville, Owner(s), and have made request for final settlement of said Contract. All persons having any claim for labor, materials, or otherwise in connection with this project should immediately notify Jay Thompson @ 334-799-3035 or Jennifer Barber (Architect) @ 334-819-6461 Mont. Adv. 8/4, 8/11, 8/18, 8/25/2018

IN RE: THE ESTATE OF ) IN THE PROBATE COURT OF ) HAZEL N. BOLES, ) AUTAUGA COUNTY, ALABAMA ) Deceased, ) CASE NO. 2018-118 NOTICE OF APPOINTMENT TO BE PUBLISHED BY EXECUTRIX Letters Testamentary of...

IN RE: THE ESTATE OF ) IN THE PROBATE COURT OF ) HAZEL N. BOLES, ) AUTAUGA COUNTY, ALABAMA ) Deceased, ) CASE NO. 2018-118 NOTICE OF APPOINTMENT TO BE PUBLISHED BY EXECUTRIX Letters Testamentary of said deceased having been granted to the undersigned on the 20th day of July, 2018, by the Honorable Alfred Q. Booth, Judge of Probate Court of Autauga County, notice is hereby given that all persons having claims against said estate are hereby required to present the same within time allowed by law or the same will be barred. KENNETH BOLES EXECUTOR Law Office of Louis C. Colley, LLC Post Office Box 680689 Prattville, Alabama 36068 (334)365-1500 Pratt. Prog. 8/4, 8/11, 8/18/2018 3073660