Every application for development shall be accompanied
by a certified check or checks payable to the Township of Blairstown
in accordance with the following schedule of administrative charges
and escrow account deposits.

Where one application for development includes several
approval requests, the sum of the individually required administrative
charges and escrow account deposits shall be paid, with separate checks
for the total administrative charges and for the total escrow account
deposits.

It should be noted that the Land Use Board may decide
in certain instances, at the request of a prospective applicant and
at a meeting prior to the submission of the application for development,
that the required amount of the escrow account deposits for a particular
application may be more than anticipated to be needed for the review
of the subject application; in such an instance, the Board may authorize
a lesser escrow amount to be payable to the Township, provided that
the applicant nevertheless agrees to pay all reasonable costs for
the review of the application. Reduction of fees will only be considered
for nonprofit organizations.

In addition to the fees and escrow deposits required
for the review of submitted applications for development, the fee
schedule also includes the fees for copies of requested items, special
meetings, rezoning requests and other items.

[Amended 4-11-2012 by Ord. No. 2012-02]

Administrative Charges

Escrow Account Deposits

1.

Informal reviews.

(a) One fifteen-minute appearance without professional review. (See § 19-802D of this chapter.)

$100

None required

(b) Any additional appearance and/or any appearance with professional review. (See § 19-802D of this chapter.)

$150 (to be credited to any subsequent application
fee)

Minor: $1,000 Major: $2,000

2.

Subdivisions.

(a) Minor subdivision plat

$150

$500 per lot

(b) Preliminary major subdivision plat

$250

$750 per lot, provided that a maximum $20,000
initially shall be deposited

(c) Final major subdivision plat

$200

$250 per lot, provided that a maximum $10,000
initially shall be deposited

(d) Amended minor, preliminary major and/or
final major subdivision plat

$150

$300 per lot, provided that a maximum $10,000
initially shall be deposited

(e) Request for reapproval or extension of time

$150

$750

3.

Site plans.

(a) Minor site plan

$150

$500/acre or part thereof

(b) Preliminary major site plan

$300

$2,000/acre or part thereof, provided that a
maximum $20,000 initially shall be deposited

(c) Final major site plan

$200

$1,000/acre or part thereof, provided that a
maximum $10,000 initially shall be deposited

(d) Amended minor, preliminary major and/or
final major site plan

$150

1/2 of the amount otherwise calculated for a
minor site plan, preliminary major site plan or final major site plan,
as the case may be

(e) Request for reapproval or extension of time

$150

$750

4.

Rezoning requests.

(a) One fifteen-minute appearance without professional
review

$100

None required

(b) One fifteen-minute appearance with professional
review

$300

$5,000

5.

Conditional uses (in addition to any fees required
for site plan or subdivision review).

$300

$500/acre or part thereof

6.

Variances.

(a) Appeals (N.J.S.A. 40:55D-70a)

$100

$1,000 each

(b) Interpretation (N.J.S.A. 40:55D-70b)

$100

$1,000 each

(c) Bulk (N.J.S.A. 40:55D-70c)

$100 per application

$1,000 each

(d) Use and others (N.J.S.A. 40:55D-70d)

$250

$2,500

(e) Permit (N.J.S.A. 40:55D-34 and 35)

$200

$1,000

(f) Request for extension of time

$150

$750

7.

Waivers.

$100

$125/first waiver plus $25/each additional waiver

8.

Special meeting of Land Use Board (as requested
by applicant).

$500

$1,000

9.

Certified list of property owners or certified
list of public utilities. (See § 19-706D(3) of this chapter.)

$0.25/name or $10, whichever is greater

None required

10.

Copy of minutes, resolutions or decisions. (See
§ 19-706E and 19-708C of this chapter.)

$0.75/page for first 1 to 10 pages; $0.50/page
for pages 11 to 20 and $0.25/ page for any additional pages

None required

11.

Transcription of meeting proceedings. (See § 19-706E
of this chapter.)

The escrow account deposits noted in this § 19-901 of the chapter are required to pay for the costs of professional services including engineering, planning, legal and other expenses connected with the review of submitted materials, including any traffic engineering review or other special analysis related to the Township's review of the submitted materials, or any necessary studies regarding off-tract improvements.

Said review escrows may be commingled with similar
escrows from other applicants, but accurate accounts and records shall
be kept so as to identify the particular escrows and charges made
against the same.

An applicant is responsible to reimburse the Township
of Blairstown for all expenses of professional personnel incurred
and paid by the Township for the review process of an application
for development before a municipal agency, such as, but not limited
to:

Charges for reviews by professional personnel of applications,
plans and accompanying documents currently pending before the municipal
agency, or the review of an applicant's compliance with the conditions
of any approval to an application for development by a municipal agency,
or the review of any requests made by the applicant for modifications
or amendments to the submitted material, provided that the professional
shall not review items which are subject to approval by any state
governmental agency and not under municipal jurisdiction, except to
the extent consultation with the state agency is necessary due to
the effect of state approvals on the proposed subdivision or site
plan;

Each applicant shall agree to pay all reasonable costs
for professional review of the application. All such costs for review
must be paid before any approved plat, plan or deed is signed and
before any zoning permit, construction permit, certificate of occupancy,
and/or other permit is issued.

Payment by the Township of Blairstown of any bill
rendered by a professional to the municipality with respect to any
service for which the municipality is entitled to reimbursement under
this chapter shall in no way be contingent upon receipt by the municipality
of reimbursement from the applicant, nor shall any payment to a professional
be delayed pending the reimbursement from an applicant.

If an applicant desires a court reporter, the cost
for taking testimony and transcribing it and providing a copy of the
transcript to the Township shall be at the expense of the applicant
who also shall arrange for the reporter's attendance.

The developer has entered into a developer's agreement with the Township of Blairstown, in a form satisfactory to the Township Attorney and authorized by the Township Committee, requiring the installation and maintenance by the developer and its successors in interest of the public improvements, imposing such limitations, and/or staging of, the development of the subdivision as are necessary to ensure orderly construction of the public improvements, and assuring the installation of the public improvements on or before an agreed date by the filing of a performance guarantee in accordance with Subsection 19-902D hereinbelow.

No construction permit shall be issued for any building within the subdivision until the developer has completed the following public improvements in accordance with the approved subdivision plans and construction plans required by Subsection 19-902E(4) hereinbelow:

All required utility installations and their
appurtenances, including water mains, drainage and detention facilities,
culverts, storm sewers, sanitary sewers or dry sewers and public improvements
of open space;

Filed with the Township of Blairstown a performance guarantee in accordance with Subsection 19-902D of this section, sufficient in amount to cover the cost of all remaining required improvements, as estimated by the Township Engineer, and assuring the installation of said improvements on or before an agreed date and as hereinafter provided.

Unless provided otherwise elsewhere in this chapter,
the remaining required improvements shall be at least 50% completed
as to each category set forth in the performance guarantee within
one year from the date of final approval or by such time as 50% of
the lots in the section in question have been conveyed in any manner
by the developer, whichever shall first occur. At least 75% of the
improvements shall be completed as to each category as set forth in
the performance guarantee within 18 months from the date of final
approval, or at such time as 75% of the lots in the section in question
have been conveyed in any manner by the developer; whichever shall
first occur. Such improvements shall be 100% completed and accepted
by the Township within two years from the date of final approval or
at such time as all of the lots in the section in question shall first
occur.

The developer, with the approval of the Land Use Board,
has entered into a developer's agreement with the Township of Blairstown
in a form satisfactory to the Township Attorney and authorized by
the governing body:

Imposing such limitations upon, and/or staging of, the development of the site as are necessary to ensure orderly construction of the public improvements on or before an agreed upon date by the filing of a performance guarantee in accordance with Subsection 19-902D of this chapter.

Requirements specific to minor subdivisions and minor site plans. In the case of a minor site plan and/or minor subdivision, in the event that the developer elects to complete all improvements without posting the performance guarantee specified in Subsection 19-902D hereinbelow, no construction shall be commenced until a finalized plan is submitted and signed, incorporating all conditions of approval.

All site improvements under this subsection must be
completed prior to the issuance of a certificate of occupancy, or
within 120 days of a temporary certificate of occupancy in the instance
where a performance guarantee covering the balance of the uncompleted
improvements has been posted.

A performance guarantee estimate shall be prepared
by the Township Engineer for review and approval, setting forth all
required public improvements as determined by the Board and their
estimated cost, provided that no performance guarantee shall be required
for the installation of utilities, when said utility improvements
will be installed by the applicable utility company. Any adjustment
in the amount of the performance guarantee shall be approved by resolution
of the Township Committee.

The cost of the installation of the required improvements
shall be estimated by the Township Engineer based on documented construction
costs for public improvements prevailing in the general area of the
Township. The developer may appeal the Township Engineer's estimate
to the Township Committee. The Township Committee shall decide the
appeal within 45 days of receipt of the appeal in writing by the Township
Clerk. After the developer posts a guarantee with the Township based
on the cost of the installation of improvements as determined by the
Township Committee, he/she may institute legal action within one year
of the posting in order to preserve the right to a judicial determination
as to the fairness and reasonableness of the amount of the guarantee.

The developer shall present two copies of the performance
guarantee in an amount equal to 120% of the approved construction
cost performance guarantee estimate for approval as to form and execution
by the Township Attorney; additional copies of the performance guarantee
shall be forwarded by the owner to the Land Use Board Attorney. The
performance guarantee estimates, as prepared by the Township Engineer
and approved by the Township Committee, shall be appended to each
performance guarantee posted by the obligor.

The performance guarantee shall be made payable and
deposited to the Township of Blairstown and shall be in the form of
cash, irrevocable letter of credit in accordance with N.J.S.A. 40:55D-53.5,
a certified check, a performance bond provided by an acceptable surety
company licensed to do business in the State of New Jersey and with
the developer as principal, or in another form of guarantee acceptable
the Township.

The Township shall issue its receipt for such
deposits and shall cause the same to be deposited in the name of the
Township to be retained as security for completion of all requirements
and to be returned to the owner on completion of all required work
or, in the event of default on part of the developer, to be used by
the Township to pay the cost and expense of obtaining completion of
all requirements.

The developer shall provide a written agreement from his/her lending institution stating that the lending institution agrees to the time period(s) required for the completion of the improvements and to the release of the guarantee by the Township Committee in accordance with Subsection 19-902G of this section.

In the case of an irrevocable letter of credit,
each such letter of credit shall comply with the "Uniform Customs
and Practices for Documentary Credits" (1984 Revision), International
Chamber of Commerce, Publication No. 400, and shall be issued or confirmed
by a New Jersey banking institution. Additionally, the form of any
irrevocable letter of credit shall be substantially similar to the
form letter of credit furnished the developer by the Township Clerk
and as approved by resolution of the Township Committee.

In the case of surety bonds, the developer shall
be the principal, and the bond shall be provided by a surety company
operating pursuant to N.J.S.A. 17:17-1 et seq. Moreover, proof of
such valid certificate shall be furnished to the Township of Blairstown
at the time the surety bond is submitted to the Township. Additionally,
the form of the surety bond shall be identical to the form letter
of bond furnished to the developer by the Township Clerk and as approved
by resolution of the Township Committee.

In the event of default, the 10% cash shall
be first applied to the completion of the requirements and any bidding
and legal costs associated therewith, and the remaining 90% cash,
letter of credit, surety bond, or other form of guarantee shall thereafter
be resorted to, if necessary, for the completion of the requirements
and any additional bidding and legal costs associated therewith.

The developer has satisfied all conditions of approval
required by the Board's resolution of memorialization granting subdivision
and/or site plan approval and all revisions to the submitted plat
or plan required by the Board at the time of subdivision or site plan
approval have been filed with and approved by the Township Engineer
and any other individual or group as may have been specified by the
Board in the applicable resolution of memorialization granting subdivision
and/or site plan approval;

Regarding major subdivisions only, the developer has posted the sales map as required by § 19-805 of this chapter in a prominent location in all offices from which sales of property in the subdivision development will be conducted.

All public improvements and utility installations for site plans, subdivisions, plot plans and other realty improvements shall be inspected during the time of their installation under the supervision of the Township Engineer and/or other applicable officials or professionals serving the Township of Blairstown in order to insure satisfactory completion. The cost of said inspection shall be the responsibility of the developer who shall deposit with the Chief Financial Officer of the Township inspection fees in an amount not to exceed, except for extraordinary circumstances, the greater of $500 or 5% of the cost of the improvements as determined by the Township Engineer in accordance with Subsection 19-902D(2) of this section, provided that:

For those developments for which the reasonably
anticipated inspection fees are less than $10,000, the fees may, at
the option of the developer, be paid in two installments. The initial
amount deposited by the developer shall be 50% of the reasonably anticipated
fees. When the balance of deposit drops to 10% of the reasonably anticipated
fees because the amount deposited by the developer has been reduced
by the amount paid to the Township Engineer for the inspection(s),
the developer shall deposit the remaining 50% of the anticipated inspection
fees.

For those developments for which the reasonably
anticipated inspection fees are $10,000 or greater, the fees may,
at the option of the developer, be paid in four installments. The
initial amount deposited by the developer shall be 25% of the reasonably
anticipated fees. When the balance of deposit drops to 10% of the
reasonably anticipated fees because the amount deposited by the developer
has been reduced by the amount paid to the Township Engineer for the
inspection(s), the developer shall make additional deposits of 25%
of the anticipated inspection fees.

The inspection escrow shall be deposited by the Chief
Financial Officer of the Township, or his/her designee, in an account
for such purposes under the sole control of the Township. Said inspection
escrows may be commingled with similar escrows from other developers,
but accurate accounts and records shall be kept so as to identify
the particular escrows and charges made against the same. The inspection
escrow funds shall be used solely for payment of inspection fees,
expenses and costs of the Township Engineer on behalf of the Township
during the course of construction.

The Township Engineer shall not perform any inspection if sufficient funds to pay for those inspections are not on deposit. Failure of the developer to deposit the required inspection fees in accordance with Subsection 19-902F(1) of this section hereinabove will subject the developer to a stop-work order and/or suspension of construction permits.

In no case shall any paving work be done without permission
from the Township Engineer. At least two working days notice shall
be given to the Township Engineer prior to any construction so that
he/she or a qualified representative may be present at the time the
work is to be done.

Streets shall not be paved with a top course until
all heavy construction is completed and, if determined by the Township
Engineer to be necessary, the macadam base course has first been restored.
Shade trees shall not be planted until all grading and earth moving
is completed. The placing of surveyor's monuments shall be among the
last operations.

The Township Engineer's office shall be notified at
least two working days prior to the commencement of the following
phases of work so that he/she or a qualified representative may inspect
the work; the Township Engineer shall, in turn, notify the landscape
architect designated by the Board, if applicable, regarding any seeding
and planting:

When designated by the Board, the landscape architect
shall witness and approve landscaping in a designated area or on a
typical lot within a development as deemed appropriate and necessary
and/or as directed by the Township Engineer. A follow-up inspection
when the entire site or phase of development is completed shall be
conducted in order to confirm compliance for either a phase of development
or the entire project:

Plantings shall be checked for compliance with
approved plans; i.e., correct quantity, size, species and location.
Any change or modifications to the approved plans must be reviewed
and approved by the landscape architect designated by the Board.

Lawns shall be inspected for adequate coverage
of healthy, vigorously growing grass which is relatively free of weeds
and void of bare spots larger than one square foot in area. Bare spots
greater than one square foot in area shall be reseeded or resodded
and reinspected until acceptable coverage is achieved.

Upon completion of the landscaping, the landscape
architect shall check for compliance with the landscape plans approved
by the Board. A punch list of outstanding or unsatisfactory items
shall be compiled with copies given to the developer and the Township
Engineer, and a final sign-off shall be given after necessary remedial
work.

Upon successful completion of all landscape
work, a written recommendation shall be forwarded by the landscape
architect to the Township Engineer to be included in the inspection
report to the Township Committee before the release of performance
guarantees.

Any improvement installed contrary to the plan or plat approval by the Township shall constitute just cause by the approving authority or designated official to void or deem voidable the municipal approval. Moreover, if a certificate of occupancy or construction permit is issued by a Township official pursuant to § 19-1002E of this chapter, such certificate or permit does not indicate acceptance by the Township of any deviation(s) from the plan or plat as approved by the Board.

Inspection by the Township of the installation
of improvements and utilities shall not operate to subject the Township
of Blairstown to liability for claims, suits or liability of any kind
that may at any time arise because of defects or negligence during
construction or at any time thereafter; it being recognized that the
responsibility to maintain safe conditions at all times during construction
and to provide proper utilities and improvements is upon the owner
and his contractor, if any.

Upon substantial completion of all required street improvements (except for the top course) and appurtenant utility improvements, and the connection of same to the public system, the obligor may request of the Township Committee in writing, by certified mail in care of the Township Clerk, that the Township Engineer prepare in accordance with the itemized cost estimate prepared by the Township Engineer and appended to the performance guarantee pursuant to Subsection 19-902D(3) of this chapter, a list of all uncompleted or unsatisfactory completed improvements.

If such a request is made, the obligor shall
send a copy of the request to the Township Engineer. The request shall
indicate which improvements have been completed and which improvements
remain uncompleted in the judgment of the obligor.

The Township Engineer shall inspect all the
improvements covered by the obligor's request and shall file a detailed
list and report, in writing, with the Township Committee, and shall
simultaneously send a copy thereof to the obligor not later than 45
days after receipt of the obligor's request.

If the Township Engineer fails to send or provide
the list and report, as requested by the obligor, within 45 days from
the receipt of the request, the obligor may apply to the Court in
a summary manner for an order compelling the Township Engineer to
provide the list and report within a stated time and the cost of applying
to the Court, including reasonable attorney's fees, may be awarded
to the prevailing party.

The list prepared by the Township Engineer pursuant to Subsection 19-902F(11) hereinabove, shall state, in detail, with respect to each improvement determined to be incomplete or unsatisfactory, the nature and extent of the incompleteness of each incomplete improvement or the nature and extent of, and remedy for, the unsatisfactory state of each completed improvement determined to be unsatisfactory. The report prepared by the Township Engineer shall identify each improvement determined to be complete and satisfactory together with a recommendation as to the amount of reduction to be made in the performance guarantee relating to the completed and satisfactory improvement, in accordance with the itemized cost estimate prepared by the Township Engineer and appended to the performance guarantee pursuant to Subsection 19-902D(3) of this section.

Release. The Township Committee, by resolution, shall either approve the improvements determined to be complete and satisfactory by the Township Engineer, or reject any or all of these improvements upon the establishment in the resolution of cause for rejection, and shall approve and authorize the amount of reduction to be made in the performance guarantee relating to the improvements accepted, in accordance with the itemized cost estimate prepared by the Township Engineer and appended to the performance guarantee pursuant to Subsection 19-902D(3) of this section. This resolution shall be adopted not later than 45 days after receipt of the list and report prepared by the Township Engineer.

Upon adoption of the resolution by the Township Committee,
the obligor shall be released from all liability pursuant to its performance
guarantee, with respect to those approved improvements, except for
that portion adequately sufficient to secure completion or correction
of the improvements not yet approved, provided that 30% of the amount
of the performance guarantee posted may be retained to ensure completion
and acceptability of all improvements and, furthermore, that the 30%
retained may be applied against all improvements, regardless of when
completed.

In the event that the obligor has made a cash deposit
with the Township or approving authority as part of the performance
guarantee, then any partial reduction granted in the performance guarantee
shall be applied to the cash deposit in the same proportion as the
original cash deposit bears to the full amount of the performance
guarantee.

If any portion of the required improvements is rejected, the obligor shall complete or correct such improvements and, upon completion or correction, shall notify the Township Committee as specified in Subsection 19-902F(11) of this section and the same procedures shall be followed as in the first instance.

Prior to the approval by the Township Committee of
the final reduction and release of the performance guarantee, all
easements and open space shall be conveyed to the Township or such
other guarantee as specified on the final plat by deed containing
a metes-and-bounds legal description.

If the Township Committee fails to approve or reject the improvements determined by the Township Engineer to be complete and satisfactory or reduce the performance guarantee for the complete and satisfactory improvements within 45 days from the receipt of the Township Engineer's list and report, the obligor may apply to the Court in a summary manner for an order compelling, within a stated time, approval of the complete and satisfactory improvements and approval of a reduction in the performance guarantee for the approvable complete and satisfactory improvements in accordance with the itemized cost estimate prepared by the Township Engineer and appended to the performance guarantee pursuant to Subsection 19-902D(3) of this section, and the cost of applying to the Court, including reasonable attorney's fees, may be awarded to the prevailing party.

Conditions and acceptance of improvements. The approval
of any application for development by the Township of Blairstown shall
in no way be construed as acceptance of any street or drainage system
or other improvement, nor shall said approval obligate the Township
in any way to exercise jurisdiction over such street or drainage system
or other improvement. Moreover, no improvements shall be accepted
by the Township Committee unless and until all of the following conditions
have been met:

The final application for development shall have been
approved by the Land Use Board and the developer shall have submitted
an affidavit, signed by a licensed New Jersey professional land surveyor,
certifying that all required monuments have been set in accordance
with the Map Filing Law[1] and any approved subdivision plat;

The Township Engineer shall have certified in writing
that the improvements are completed and that they comply with the
requirements of this chapter and the terms of the final application
for development approved by the Board;

The owner shall have filed with the Township Committee a maintenance guarantee in an amount equal to and not more than 15% of the cost of installing the improvements, the cost to be determined by the Township Engineer in accordance with Subsection 19-902D(2) of this section hereinabove.

The maintenance guarantee shall run for a period
of two years, provided that the maintenance guarantee shall not terminate
until the Township Committee has authorized its release pursuant to
a recommendation by the Township Engineer.

The requirements for a maintenance guarantee
may be waived by the Township Committee only if the Township Engineer
has certified that the improvements have been in continuous use for
not less than two years from the date the Township Engineer certified
completion of such improvements and that during this period the owner
has maintained the improvements in a satisfactory manner; and

An as-built plan and profiles of all utilities and
roads [two black-and-white prints to be sent to the Township Engineer
plus a Mylar copy and two black-and-white prints to be sent to the
Administrative Officer], with certification signed and sealed by a
New Jersey licensed professional engineer as to the actual construction
as approved by the Township Engineer, shall be provided.

Extension of time. The time allowed for the installation
of the improvements for which the performance guarantee has been provided
may be extended by the Township Committee by resolution, provided
that the current municipal cost of installation of such improvements
shall first be redetermined by the Township Engineer, and if such
current municipal cost is found to be greater than the cost as originally
determined, the developer shall be required, as a condition of any
such extension, to increase the amount of the performance guarantee
to an amount equal to one hundred 120% of the installation cost as
redetermined. In the event that the redetermined cost shall be less
than the cost as originally determined, and in further event that
the developer's performance guarantee exceeds one hundred 120% of
such redetermined costs, the developer shall be entitled to a reduction
of the performance guarantee to an amount equal to one hundred 120%
of such redetermined costs.

Default by developer. If the required improvements
are not completed or corrected in accordance with the performance
guarantee, the obligor and surety, if any, under the performance guarantee
shall be liable thereon to the Township for the cost of the improvements
not completed or constructed, and the Township, either prior to or
after receipt of the proceeds thereof, may complete the improvements.
Such completion or correction of improvements shall be subject to
the public bidding requirements of the Local Public Contracts Law,
P.L. 1971, c. 198.[2]

For purposes of this subsection, "default" shall mean
failure to install the improvements in accordance with Township standards
of construction, including but not limited to failure to install the
improvements prior to the expiration of the performance guarantee.

The Township Engineer's certification that the developer
has defaulted in compliance with the required standards of construction
and installation of improvements shall be the basis for Township Committee
action which rejects the improvements, withholds approval, withholds
construction permits or formally declares default and authorizes collection
on the performance guarantee.

Penalties. In addition to the penalties for violation of this chapter in accordance with § 19-1006, the Township Engineer, or another Township official designated by the Township Committee, is specifically authorized to require the replacement or restoration of any lands, buildings, structures and site improvements (including clearing, whether on site or off site) or of any other work commenced or continued on any site for which an approval is required pursuant to this chapter in violation of any stop-construction order or the standards for construction as established by the Township.

The Township of Blairstown or the Land Use Board shall
not bill the applicant or charge any established escrow account for
any municipal clerical or administrative functions, overhead expenses,
meeting room charges, or for any other municipal costs and expenses
except, and subject to, the following:

If the salary, staff support and overhead for a municipal
professional are provided by the Township of Blairstown, the charge
shall not exceed 200% of the sum of the products resulting from multiplying
the hourly base salary of each of the professionals (which shall be
established annually by ordinance) by the number of hours spent by
the respective professional upon review of the application for development
or for the inspection of the developer's improvements, as the case
may be;

If the salary, staff support and overhead for a municipal
professional are not provided by the Township of Blairstown, the charge
shall be at the same rate as all other work of the same nature by
the professional for the municipality when fees are not reimbursed
or otherwise imposed on applicants or developers; and

If the Township of Blairstown retains a different
professional or consultant in the place of the professional originally
responsible for development within the municipality, for the review
of an application for development or for the inspection of improvements,
the Township of Blairstown or the Land Use Board shall be responsible
for all time and expenses of the new professional to become familiar
with the application or the project, and the municipality or municipal
agency shall not bill the applicant or charge any established escrow
account for any such service.

The Chief Financial Officer of the Township, or his/her
designee, shall make all of the payments to professionals for services
rendered to the Township of Blairstown or to the Land Use Board for
the review of applications for development and the inspection of improvements
and shall administer the review and escrow deposits as follows:

Each payment charged to a deposit for the review of
applications for development and for the inspection of improvements
shall be pursuant to a voucher from the professional in accordance
with the following:

Each voucher shall identify the personnel performing
the service, the date each service is performed, the hours spent to
one-quarter-hour increments, the hourly rate of the professional,
and the expenses incurred.

The Chief Financial Officer of the Township shall
prepare and send to the applicant a statement which shall include
an accounting of the funds listing all deposits, interest earnings,
disbursements and the cumulative balance of the escrow account; this
information shall be provided on a quarterly basis if the monthly
charges are $1,000 or less, or on a monthly basis if the monthly charges
exceed $1,000.

If an escrow account or deposit contains insufficient
funds to enable the Township of Blairstown or the Land Use Board to
perform the required application reviews or improvement inspections,
the Chief Financial Officer of the Township shall provide the applicant
with a written notice of the insufficient escrow or deposit balance.

In order for work to continue on the development
or the application, the applicant, within 10 days of the written notice,
shall post a deposit to the account in an amount to be agreed upon
between the Township of Blairstown, the Land Use Board and the applicant.

With regard to review fees, if the applicant
fails to make said deposit within the time prescribed herein, the
Land Use Board shall be authorized to dismiss the application without
prejudice subject to the right of the applicant to seek reinstatement
by notice to the Board that said deposits have been posted.

With regard to inspection fees, the Township
Engineer shall not perform any inspection if sufficient funds to pay
for the inspections are not on deposit, provided that any required
health and safety inspections shall be made and charged back against
the replenishment of funds. Failure to post and maintain inspection
fee deposits in accordance with these requirements will subject the
developer to a stop-work order and/or suspension of construction permits.

Whenever an amount of money in excess of $5,000 is deposited by an applicant or developer with the Township for professional services employed by the Township for the review of submitted applications for development pursuant to § 19-901 of this chapter, or for inspections pursuant to Subsection 19-902F of this section, or to satisfy the guarantee requirements pursuant to Subsection 19-902D of this section, the money, until repaid or applied to the purposes for which it is deposited, including the applicant's or developer's portion of the interest earned thereon, except as otherwise provided in this section, shall continue to be the property of the applicant or developer and shall be held in trust by the municipality in accordance with the following:

The money shall be deposited by the Township of Blairstown
in a banking institution or savings and loan association in New Jersey
insured by an agency of the federal government, or in any other fund
or depository approved for such deposits by the state.

The Township of Blairstown shall not be required to
refund an amount of interest paid on a deposit which does not exceed
$100. However, if the amount exceeds $100, that entire amount shall
belong to the applicant or developer and shall be refunded to him/her
by the Township annually or at the time the deposit is repaid or applied
to the purposes for which it was deposited, as the case may be; except
that the Township may retain for administrative expenses a sum equivalent
to not more than 33 1/3% of that entire amount which shall be
in lieu of all other administrative and custodial expenses.

Required improvements. Applicants shall be required,
as a condition for approval of a subdivision, site plan or conditional
use, to pay their pro rata share of the cost providing reasonable
and necessary street improvements and/or water, sewerage and drainage
facility improvements, and any necessary easements therefor located
outside the property limits of the subject premises, but indicated
in the Township Master Plan and necessitated or required by construction
or improvements within such subdivision or development. The following
criteria shall be utilized in determining the developer's proportionate
pro rata monetary share for the necessary off-tract developments.

Improvements to be constructed at the expense of the
developer. In cases where the need for an off-tract improvement is
reasonably created by the proposed subdivision or development and
where no other property owners receive a special benefit thereby (as
opposed to a mere incidental benefit), the applicant may be required,
as a condition of approval and at the applicant's sole expense, to
acquire and/or improve lands outside the tract and dedicate such lands
to the Township of Blairstown or Warren County or, in lieu thereof,
require the subdivider or developer to deposit with the Township a
sum of money sufficient to allow the Township to acquire and/or improve
such lands on conditions it may deem appropriate under the circumstances.

General standards for other improvements. In cases
where the need for any off-tract improvement to be implemented now
or in the future is reasonably necessitated by the proposed development
application, and where it is determined that properties outside the
development also will be benefited by the improvement, the following
criteria, together with the provisions or rules and regulations of
the Township of Blairstown or any department thereof, may be utilized
in determining the developer's proportionate share of such improvements:

Sanitary sewers. For distribution facilities, including
the installation, relocation or replacement of collector, trunk and
interceptor sewers and the installation, relocation or replacement
of other appurtenances associated therewith, the applicant's proportionate
share shall be computed as follows:

The capacity and the design of the sanitary
sewer system shall be based on the Rules and Regulations for the Preparation
and Submission of Plans for Sewerage Systems, New Jersey State Department
of Environmental Protection, and all Blairstown Township sewer design
standards, including infiltration standards.

The capacity of the existing system to serve
the entire improved drainage area shall be computed. If the system
is able to carry the total development drainage basin, no improvement
or enlargement cost will be assigned to the developer although some
charges including, but not limited to, capacity charges may be imposed.
If the existing system does not have adequate capacity for the total
development drainage basin, the pro-rated enlargement or improvement
share shall be computed as follows:

Roadways. For street widening, alignment, channelization
of intersections, construction of barriers, new or improved traffic
signalization, signs, curbs, sidewalks, trees, utility improvement
uncovered elsewhere, the construction or reconstruction of new or
existing streets and other associated streets or traffic improvements,
the applicant's proportionate cost shall be determined as follows:

The applicant shall furnish a plan for the proposed
off-tract improvements, which shall include the estimated peak-hour
traffic generated by the proposed development. The ratio of the peak-hour
traffic generated by the proposed development to the future peak-hour
traffic shall form the basis of the proportionate share. The pro-rated
share shall be computed as follows:

Drainage improvements. For the stormwater and drainage
improvements, including the installation, relocation or replacement
of storm drains, culverts, catch basins, manholes, riprap or improved
drainage ditches and appurtenances thereto and the relocation or replacement
of other storm drainage facilities or appurtenances associated therewith,
the applicant's proportionate share shall be determined as follows:

The capacity and design of the drainage system
to accommodate stormwater runoff shall be based on a method described
in Urban Hydrology for Small Watersheds, Technical Release 55, Soil
Conservation Service USDA, January 1975, as amended, and shall be
computed by the developer's engineer and approved by the Township
Engineer.

The capacity of the enlarged, extended or improved
system required for the subdivision or development and areas outside
of the subdivision or development shall be computed by the developer's
engineer and be subject to the approval of the Township Engineer.
The plans for the improved system shall be prepared by the developer's
engineer and the estimated cost of the enlarged system shall be calculated
by the Township Engineer.

Where no public water is accessible as defined in § 19-519C(1) of this chapter, the applicant (in addition to complying with § 19-519B shall deposit funds in escrow with the Township of Blairstown in an amount equal to the cost of connecting the subdivision to an existing public water supply system calculated on the basis of 200 feet per unit.

The escrow amount shall be calculated by determining
the costs of providing such water main extension as charged by the
public water utility for such service, including, but not limited
to, materials, installation, taxes, appurtenances, surcharges, if
any, etc.

When, pursuant to § 19-501D(1) of
this chapter, an applicant does not install an underground water storage
tank system and ancillary fire protection wells, an applicant shall
be required to pay is pro rata share of the cost of the installation
of the underground water storage tank system.

Where the cost of such system exceeds the pro
rata share, the residual cost shall be provided by the Township of
Blairstown from the deposited escrow funds, according to the zones
delineated within Schedule A attached to § 19-500 of this
chapter.

The escrow deposit for each lot
shall be made no later than the time application for a building permit
for the principal structure to be located on the lot is made, and
no building permit shall be issued until the escrow deposit is made.

Escrow accounts. Where the proposed off-tract improvement
is to be undertaken at a future date, funds required for the improvement
shall be deposited to the credit of the Township of Blairstown in
a separate account until such time as the improvement is constructed.
In lieu of a cash escrow account, developer's may present irrevocable
letters of credit for the term required in a form acceptable to the
Township Attorney.

Where applications for development suggest the need
for off-tract improvements, whether to be installed in conjunction
with the development in question or otherwise, the Land Use Board
shall forthwith forward to the Township Committee a list and description
of all such improvements together with a request that the Township
Committee determine and advise the Board of the procedure to be followed
in construction or installation thereof, including timing. The Board
shall defer final action upon the subdivision or site plan until receipt
of the Township Committee determination or the expiration of 90 days
after the forwarding of such list and description to the Township
Committee without determination having been made, whichever comes
sooner.

The Township Committee, within 90 days after receipt
of said list and description, shall determine and advise the Land
Use Board concerning the procedure to be followed and advise the Board
with regard to suggested conditions of approval, if any, to adequately
protect the municipality.

In the event that the Land Use Board is required by
statute to act upon the application prior to receipt of the Township
Committee's determination as to construction of off-tract improvements,
it shall request the applicant to consent to an extension of time
within which to act, of sufficient duration to enable the Township
Committee to make the aforesaid determination. In the event that the
applicant is unwilling to consent to the requested extension of time,
the Land Use Board shall, in its discretion, either itself determine
the procedure to be followed in constructing the aforesaid improvements,
or shall condition its approval upon the subsequent determination
of the Township Committee.

In all cases, developers shall be required to enter
into an agreement or agreements with Blairstown Township in regard
to off-tract improvements, in accordance with this chapter and any
other ordinances, policies, rules and regulations of the Township
of Blairstown, Warren County and the State of New Jersey and any departments,
authorities or agencies thereof.

Where properties outside the subject tract will be benefited by the improvements, the Township Committee may require the applicant to escrow sufficient funds, in accordance with Subsection 19-904D, Escrow accounts, hereinabove, to secure the developer's pro rata share of the eventual cost of providing future structural improvements based upon the standards expressed herein.

Where properties outside the subject tract will benefit
by the improvements, the Township Committee may determine that the
improvement or improvements are to be installed by the municipality
as a general improvement, the cost of which is to be borne as a general
expense. If the Township Committee shall determine that the improvement
or improvements shall be constructed or installed as a general improvement,
the Township Committee may direct the Land Use Board to estimate,
with the aid of the Township Engineer or such other persons who have
pertinent information or expertise, the amount, if any, by which the
total cost thereof will exceed the total amount by which all properties,
including the subject tract, will be specifically benefited thereby,
and the subdivider or developer shall be liable to the municipality
for such expense.

If the Township Committee shall determine that the improvement or improvements shall be constructed or installed as a local improvement, all or a part of the cost of which is to be assessed against properties benefited thereby in proportion to the benefits conferred by the improvements in accordance with Chapter 56 of Title 40 of the Statutes of the State of New Jersey, the developer may be required to sign an agreement acknowledging and agreeing to this procedure and, in addition, the Township Committee may require that the developer shall be liable to the municipality, in addition to the amount of any special assessments against the subject property for benefits conferred by the improvement or improvements, the difference between the total cost actually incurred and the total amount by which all properties, including the subject tract, are specially benefited by the improvement as the same may be determined by the Board of Improvement Assessors.

If the Township Committee shall determine that the
improvements are to be constructed or installed by the applicant,
such agreement may contain provisions, consistent with the standards
in this chapter and any other rules, regulations or policies of the
Township of Blairstown, County of Warren and the State of New Jersey
and any departments, authorities or agencies thereof with jurisdiction
therein, whereby the applicant shall be reimbursed by the municipality
or otherwise, as a result of any participation fees, connection charges,
charges paid in regard to developer's agreements with other applicants
and the like, all in accordance with an agreement between the Township
Committee and the applicant.

In determining the procedures to be followed in the
event of the submission of a list and request from the Land Use Board,
the Township Committee shall be guided by the following standards
and considerations:

The extent to which temporary measures may sufficiently
alleviate the condition or conditions requiring the off-tract improvement
and the likelihood that larger, regional or subregional facilities
will be required in the future to serve the development tract and
the general area of the municipality in which the same is located;
and